Agency: | City of Rochester |
---|---|
State: | New York |
Type of Government: | State & Local |
Category: |
|
Posted: | Mar 3, 2023 |
Due: | Mar 24, 2023 |
Publication URL: | To access bid details, please log in. |
RFP – 2025 Preventive Maintenance Project, PROJECT NO. 23137
Overview
The City of Rochester Department of Environmental Services Street Design Division is soliciting a Request for Proposals (RFP). Firms must be listed on the current NYSDOT Region 4 Local Design Service Agreement (LDSA) to be eligible to submit on this proposal. The City seeks to enter into a Professional Services Agreement for the design and preparation of engineering reports and construction contract documents. This is a federally funded milling & resurfacing project that includes the design and preparation of engineering reports and construction contract documents for improvements to two arterial streets in the City of Rochester.
Communications
All communications by parties who have an intent to submit or have submitted a proposal in response to this RFP (“Respondents”), including any questions or requests for clarifications, submission of the proposal, requests for status updates about the proposal selection process and any other inquiries whatsoever concerning this RFP shall be sent, in writing, to the following City contact(s):
Primary Contact/Project Manager: Secondary Contact:
Darin Ramsay Dominic Fekete, P.E.
darin.ramsay@cityofrochester.gov
dominic.fekete@cityofrochester.gov
585-428-6695
585-428-6767
No contact is permitted with any other City staff member with regard to this RFP during the RFP process unless specifically authorized in writing. Prohibited contact may be grounds for disqualification.
To ensure that all Respondents have a clear understanding of the scope and requirements of this RFP, the City contact(s) will respond to all timely questions submitted via e-mail to respondents who have provided an e-mail address by the question deadline stated in the RFP and post to the City website for this RFP. The City’s failure to timely respond or provide responses to any questions shall not delay or invalidate the City’s right to make a decision to award an agreement pursuant to this RFP.
The City will make every reasonable effort to keep Respondents informed about the RFP process. Notifications about timeline date changes, amendments to the RFP and other information about the RFP will be sent by e-mail to Respondents and will be posted on the City’s website for this RFP. The City’s failure to provide such information shall not delay or invalidate the City’s right to make a decision to award an agreement pursuant to this RFP.
Pre-Proposal Meeting
A Pre-Proposal Meeting will not be held. Respondents may submit questions as needed following the communication guidelines outlined above.
Submission Delivery Information
Five (5) proposal hard-copies and one (1) electronic proposal (preferably via USB storage drive) are to be submitted no later than March 24, 2023 at 4:00 p.m. to:
Holly E. Barrett, P.E.
City Engineer
City of Rochester
Department of Environmental Services,
Bureau of Architecture & Engineering
City Hall, 30 Church Street, Room 300B
Rochester, New York 14614
With GovernmentContracts, you can:
Large-Scale Renewables "Build-Ready" Site Nomination (RFI-4464) Due Date: 12/30/2025 NYSERDA RFI-4464 advances large-scale
State Government of New York
Bid Due: 12/30/2025
Charge Ready NY 2.0 Equipment and Network Qualification Process (RFQL 5312) Due Date:
State Government of New York
Bid Due: 12/31/2025
Follow Repair/Replace Overhead Cranes on Fort Drum Active Contract Opportunity Notice ID W911S224UOHCR
Federal Agency
Bid Due: 11/13/2028
Issue Date: 11/21/2023 Contract Number: PON 4701 Low Carbon Pathways for Multifamily Buildings
The New York State Contract Reporter
Bid Due: 12/31/2025