The University of North Carolina at Greensboro

Location:	North Carolina
Posted:	Feb 20, 2026
Due:	Mar 17, 2026
Agency:	State Government of North Carolina
Type of Government:	State & Local
Category:	U - Education and Training Services
Solicitation No:	SCO-SCO-25-29246-01A
Publication URL:	To access bid details, please log in.

Solicitation Number:	SCO-SCO-25-29246-01A
Project Title:	The University of North Carolina at Greensboro
Description:	Tower Village Elevator Upgrades
Opening Date:	3/17/2026 2:00 PM
Posted Date:	2/20/2026
Status:	Open
Department:	STATE OF NC - CONSTRUCTION OFFICE


Solicitation Number * SCO-SCO-25-29246-01A	Department STATE OF NC - CONSTRUCTION OFFICE	Status Reason Open
Opening Date 2026-03-17T14:00:00.0000000	Posted Date * 2026-02-19T17:01:33.0000000Z	Primary Commodity Code Construction Services
Mandatory Conference/Site Visit — —	Special Instructions An open pre-bid meeting will be held for all interested bidders on February 24, 2026 at 2:00 pm in the courtyard at Tower Village, 1541 Spring Garden St., Greensboro, NC 27412. The meeting will address project specific questions, issues, bidding procedures and bid forms.	Solicitation Type * Select RFP IFB RFI
Owner Rojan Nazari
Description Tower Village Elevator Upgrades
Description Tower Village Elevator Upgrades

Attachment Preview

Tower Village Elevator Upgrades

The University of North Carolina at Greensboro

SCO # 25-29246-01A

WHN Architects

Project # 25124

N O T I C E TO B I D D E R S

Sealed proposals will be received by UNC Greensboro in Greensboro, NC, at the Gray Home

Management House, 105 Gray Dr., Greensboro, NC 27412 up to 2:00 pm, March 17, 2026 and

immediately thereafter publicly opened and read for the furnishing of labor, material and

equipment entering into the construction of

Tower Village Elevator Upgrades

For

The University of North Carolina at Greensboro

Bids will be received for single prime contract All proposals shall be lump sum.

Pre-Bid Meeting

An open pre-bid meeting will be held for all interested bidders on February 24, 2026 at 2:00 pm

in the courtyard at Tower Village, 1541 Spring Garden St., Greensboro, NC 27412. The meeting

will address project specific questions, issues, bidding procedures and bid forms.

Parking for both the Pre-Bid Meeting and the Bid Opening is availble in McIver Parking Deck on

the UNC-G Campus.

The meeting is also to identify preferred brand alternates and their performance standards that

the owner will consider for approval on this project.

In accordance with General Statute GS 133-3, Specifications may list one or more preferred

brands as an alternate to the base bid in limited circumstances. Specifications containing a

preferred brand alternate under this section must identify the performance standards that

support the preference. Performance standards for the preference must be approved in

advance by the owner in an open meeting. Any alternate approved by the owner shall be

approved only where (i) the preferred alternate will provide cost savings, maintain or improve

the functioning of any process or system affected by the preferred item or items, or both, and (ii)

a justification identifying these criteria is made available in writing to the public.

In accordance with GS133-3 and SCO procedures the following preferred brand items are being

considered as Alternates by the owner for this project:

Owner-Preferred Add Alternate No. G-1: Provide controls as specified in Section 142400 –

Hydraulic Elevators but manufactured by MAD Elevator, Inc.

Justification of any approvals will be made available to the public in writing no later than seven

(7) days prior to bid date.

Complete plans, specifications and contract documents will be open for inspection in the offices

of UNC Greensboro and WHN Architects, PAand in the plan rooms of the Associated General

Contractors, Carolinas Branch, Raleigh, NC in the local North Carolina offices of McGraw-Hill

Dodge Corporation, and in the Eastern Regional Office of Reed

Hispanic Contractors Association of the Carolinas (HCAC) in Winston-Salem,

Charlotte and Raleigh Areas – 877-227-1680

SCO-Notice To Bidders 2010 – (Updated Dec. 2010)

NOTE: The bidder shall include with the bid proposal the form Identification of Minority Business

Participation identifying the minority business participation it will use on the project and shall

include either Affidavit A or Affidavit B as applicable. Forms and instructions are included within

the Proposal Form in the bid documents. Failure to complete these forms is grounds for

rejection of the bid. (GS143-128.2c Effective 1/1/2002.)

All contractors are hereby notified that they must have proper license as required under the

state laws governing their respective trades.

General contractors are notified that Chapter 87, Article 1, General Statutes of North Carolina,

will be observed in receiving and awarding general contracts. General contractors submitting

bids on this project must have license classification for General Contractor.

Each proposal shall be accompanied by a cash deposit or a certified check drawn on some

bank or trust company, insured by the Federal Deposit Insurance Corporation, of an amount

equal to not less than five percent (5%) of the proposal, or in lieu thereof a bidder may offer a

bid bond of five percent (5%) of the bid executed by a surety company licensed under the laws

of North Carolina to execute the contract in accordance with the bid bond. Said deposit shall be

retained by the owner as liquidated damages in event of failure of the successful bidder to

execute the contract within ten days after the award or to give satisfactory surety as required by

law.

A performance bond and a payment bond will be required for one hundred percent (100%) of

the contract price.

Payment will be made based on ninety-five percent (95%) of monthly estimates and final

payment made upon completion and acceptance of work.

No bid may be withdrawn after the scheduled closing time for the receipt of bids for a period of

30 days.

The owner reserves the right to reject any or all bids and to waive informalities.

Designer:

Owner:

WHN Architects, PA

330 W. 10th St.

Charlotte, NC 28202

704-333-9952

UNC Greensboro

1400 Spring Garden St.

Greensboro, NC 27407

SCO-Notice To Bidders 2010 (Updated Dec. 2010)

This is the opportunity summary page. It provides an overview of this opportunity and a preview of the attached documentation.

Daily notification on new contract opportunities

With GovernmentContracts, you can:

Find more opportunities and win more business
Receive daily alerts for all new bid opportunities
Get contract opportunities matched to your business

ONE WEEK FREE TRIAL

The University of North Carolina at Greensboro

Attachment Preview

See also