Westwind Lakes Park - Playground Replacement

Parks, Recreation and Open Spaces MIAMI-DADE COUNTY, FLORIDA
Capital Programs Division REQUEST FOR PRICE QUOTATION (RPQ)
275 NW 2nd Street, 4th Floor, Suite 412 Contract No: MCC 7360 Plan
Miami FL 33128 RPQ No: 2026WLPR
INVITATION TO BID
A RPQ has been issued for the work identified below. If you are interested in submitting a bid for this project, please submit your
bid via Electronic Bidding, attention to Jeffery Becar at no later than 10/20/2026 at 02:00 PM. If you have any questions, contact
Enmaily Alvarez Colina at 305/497-4832.
This RPQ is issued under the terms and conditions of the Miscellaneous Construction Contracts (MCC) Program MCC 7360 Plan.
RPQ DETAILED BREAKDOWN
Bid Due Date: 10/20/2026 Time Due: 02:00 PM Submitted Via: Electronic Bidding
Estimated Value: $514,000 (excluding Contingencies and Dedicated Allowances)
Project Name: Westwind Lakes Park - Playground Replacement
Project Location: Westwind Lakes Park - 6805 SW 152nd Ave, Miami, FL 33193
License Requirements: Primary: General Building Contractor; Building Contractor; General Engineering
Scope of Work: (Contractor must obtain and submit all permits prior to performing any work).
EXPERIENCE REQUIREMENT:
Bidder or Bidder's Subcontractor shall have completed at least two (2) projects of similar size and
scope; in lieu of the references from the Bidder or Bidder's Subcontractor, the County will
consider the references from Bidder's key personnel in accordance with Resolution No. R-1122-
21. Bidder shall provide evidence of this experience; project names; dollar values and contract
information for verification purposes. The experience of the bidding or proposing Contractors' key
personnel will be considered in assessing the Contractor's experience. This information should be
entered on form 00450 Bidder''s Statement of Qualifications and Business References,
highlighting at least two comparable projects and using additional pages as needed.
CPSI Certification Requirement:
Certified Playground Safety Inspector (CPSI) Certification held by Owner, principal or direct
employee of the company actively engaged in the scope of work.
SCOPE OF WORK: (Contractor must obtain and submit all permits prior to performing any work.)
CONTRACTOR shall review all documents, specifications, and scope of work provided by Miami-
Dade County Parks, Recreation, and Open Spaces Department for work to be completed. Furnish
all labor, equipment, and materials required to comply with the intent of the WORK described in
the contract documents including but not limited to:
1.1) Contractor shall furnish all labor, materials, tools, equipment, and supervision to completely
remove the existing playground components specified below and replace them with new,
equivalent structures. Prior to the commencement of work, the Contractor shall be solely
responsible for inspecting the site and verifying that all listed replacement parts constitute an
exact, functional swap compatible with the existing infrastructure, vertical poles and the new
design layout. Contractor is required to disassemble existing playground accessories leaving

structural poles,(to be painted by others)
1.2) Contractor shall inspect existing conditions to confirm if additional parts are required outside
scope parts list Fig.1
1.3) Contractor shall be responsible by any/all governing entities for the removal and disposal of
existing playground parts
1.4) Contractor shall provide a representative of manufacturer to oversee removal and installation
of new materials, representative will maintain compliance with manufacturer's specifications. Any
imperfection's detected by the manufacturer and/or owner will be repaired prior to completion of
project. Contractor will submit a letter of acceptance by the manufacture upon final inspection.
1.5) Contractor shall submit General Requirements with relation to product installation to include:
Performance/Scope Requirements, Submittals ,parts list ,colors and fastening system to project
manager
1.6) Prior to the commencement of any site mobilization or field operations, the Contractor shall
submit a comprehensive project baseline schedule to the Construction Manager for review and
formal acceptance. No work shall initiate until such schedule has been approved in writing by the
Construction Manager. Throughout the duration of the project, Contractor shall maintain approved
schedule to accurately reflect actual progress and reflect any delay. The Contractor shall be
required to furnish a fully updated, revised project schedule within one work week as requested
by the Construction Manager, at no additional cost to the Owner.
1.7) Contractor to submit manufacturer's warranty for all replacement parts.
1.8) Contractor must be a Certified playground inspector and manufacture installer with a valid
license/certificate . Must hold CSPI Certification
1.9) All areas affected shall be protected while any construction related activity is taking place to
prevent public access, i.e., 6 ft. construction fence, safety signs, etc. during renovation process.
The contractor shall be responsible for all property damages .All effected Sod areas are to be
restored at the completion of the project
BID DOCUMENTS AND PRE-BID MEETING ACCESS:
To receive the bid documents, contact Roberto Ciprian at Roberto.Ciprian@miamidade.gov. The
Bid Documents must be requested directly from the Parks, Recreation and Open Spaces
Department or your bid may be deemed non-responsive.
Bid Documents will be available on: 09/18/2026
REQUEST FOR CLARIFICATION/INFORMATION:
All requests for information (RFI) must be submitted in writing by 10/08/2026 to
Roberto.Ciprian@miamidade.gov and copy the Clerk of the Board at clerkbcc@miamidade.gov.
NO PHONE CALLS WILL BE ACCEPTED. RFIs submitted after the specified deadline may not
be attended to. Verbal statements made by the County or the Owner's Representative that are
not contained in an RPQ or addendum to the RPQ are not binding on the County and should not
form any basis for a bidder's response to an RPQ.
INDEMNIFICATION AND INSURANCE REQUIREMENTS:
Refer to Project Manual Volume I - 00800 Supplemental General Conditions, Article 1.8 for
requirements.
PRE-BID CONFERENCE:
A Pre-Bid Conference is scheduled for September 24, 2026 @ 10:00 AM at Westwind Lakes Park
- 6805 SW 152nd Ave, Miami, FL 33193.

Document Pickup: Contact: Roberto.Ciprian@miamidade.gov Phone No: Date: 9/18/2026
Location: To receive the bid documents contact: Roberto.Ciprian@miamidade.gov
Pre-Bid Meeting:: YES Mandatory: No Date: 9/24/2026 Time: 10:00 AM
Location: Virtual Conference via Computer or Phone
Site Meeting: YES Mandatory: YES Date: 9/24/2026 Time: 10:00 AM
Location: Contractor to visit site prior to bid submittal - Westwind Lakes Park - 6805 SW 152nd
Ave, Miami, FL 33193
Bid shall be submitted to: Contact: Jeffery Becar
Address: via email in PDF format to Jeffery.BecarCavero@miamidade.gov
Email: Jeffery.BecarCavero@miamidade.gov FAX # : 305-755-7840
Type of Contract: Multiple Trade Method of Award: Lowest Responsible Bidder
Method of Payment: Scheduled Monthly Payments Insurance Required: YES
Additional Insurance Required: NO If Yes - Minimum Coverage:
Performance & Payment Bond Required: YES Bid Bond Required: YES
Davis Bacon: YES Maintenance Wages: NO AIPP: NO Amount:
DBE Participation: NO Percentage: 0.00% DBE Subcontractor Forms Required: NO
SBE-S Requirements NO Percentage: 0.00%
SBE-Services Commodity Set-Aside NO If Yes, Service =
SBE-G Requirements NO Percentage: 0.00%
SBE-Goods Commodity Set-Aside NO If Yes, Goods =
Liquidated Damages: YES $$ Per Day: $250.00
For RPQ's less than $10,000, if no LD rate is specified, the County reserves the right to assess actual damages in lieu of LDs.
Design Drawing Included: NO Shop Drawing Included: NO Specifications Included: YES
Anticipated Start Date: 11/30/2026 Calendar Days for Project Completion: 365
Comments:

DISCLOSURE:
* Contractor shall indemnify and hold harmless the County and its officers, employees, agents and instrumentalities from
any and all liability, losses or damages, including attorneys' fees and costs of defense, which the County or its officers,
employees, agents or instrumentalities may incur as a result of claims, demands, suits, causes of actions or proceedings
of any kind or nature arising out of, relating to or resulting from the performance of this Agreement by the Contractor or its
employees, agents, servants, partners principals or subcontractors. Contractor shall pay all claims and losses in
connection therewith and shall investigate and defend all claims, suits or actions of any kind or nature in the name of the
County, where applicable, including appellate proceedings, and shall pay all costs, judgments, and attorney's fees which
may issue thereon. Contractor expressly understands and agrees that any insurance protection required by this
Agreement or otherwise provided by the Contractor shall in no way limit the responsibility to indemnify, keep and save
harmless and defend the County or its officers, employees, agents and instrumentalities as herein provided.
The Contractor shall furnish to Parks, Recreation and Open Spaces, Capital Programs Division, 275 NW 2nd Street,
4th Floor, Suite 412, Miami FL 33128, Certificate(s) of Insurance which indicate that insurance coverage has been
obtained which meets the requirements as outlined below:
A. Worker's Compensation Insurance for all employees of the Contractor as required by Florida Statute 440.
a. If applicable should include coverage required under the U.S. Longshoremen and Harbor Workers' Act (USL&H)
and/or Jones Act for any activities on or about navigable water.
B. Commercial General Liability in an amount not less than $300,000 per occurrence, and $600,000 in the aggregate.
Miami-Dade County must be shown as an additional insured with respect to this coverage.
C. Automobile Liability Insurance covering all owned, non-owned and hired vehicles used in connection with the work, in
an amount not less than $300,000 combined single limit per occurrence for bodily injury and property damage.
*Under no circumstances are Contractors permitted on the Aviation Department, Aircraft Operating Airside (A.O.A) at
Miami International Airport without increasing automobile coverage to $5 million. Only vehicles owned or leased by a
company will be authorized. $1 million limit applies at all other airports.