54-TJK-07-PR35943, Caswell Janitorial Proposal 2026

Bid No. 54-TJK-07-PR35943 1 Caswell County Janitorial
STATE OF NORTH CAROLINA
DEPARTMENT OF TRANSPORTATION
REQUEST FOR PROPOSAL
DATE AND TIME OF BID OPENING: JULY 29, 2026 AT 2:00 P.M.
BID QUESTIONS: JULY 15, 2026 AT 5:00 P.M.
BID PROPOSAL NO.: 54-TJK-07-PR35943
WBS ELEMENT NO.: 7RE.101718
COUNTY: CASWELL - DIVISION 7
LOCATION: US 29 AT THE NC 700 INTERSECTION, EXIT 167, ONE (1)
MILE SOUTH OF THE NC/VA STATELINE
TYPE OF WORK: CUSTODIAL OPERATIONS AND MAINTENANCE OF REST
AREA
DATE OF AVAILABILITY: OCTOBER 1, 2026
COMPLETION DATE: SEPTEMBER 30, 2027
SMALL BUSINESS CERTIFICATION MANDATORY

Bid No. 54-TJK-07-PR35943 2 Caswell County Janitorial
PROPOSAL
FOR THE CONSTRUCTION OF
BID NO. 54-TJK-07-PR35943IN CASWELL COUNTY - DIVISION 7, NORTH CAROLINA
JULY 8, 2026
DEPARTMENT OF TRANSPORTATION,
RALEIGH, NORTH CAROLINA
The Bidder has carefully examined the location of the proposed work to be known as BID NO 54-TJK-07-PR35943;
has carefully examined the plans and specifications, which are acknowledged to be part of the proposal, the special
provisions, the proposal, the form of contract; and thoroughly understands the stipulations, requirements and
provisions. The undersigned bidder agrees to bound upon his execution of the bid and subsequent award to him by
the Department of Transportation in accordance with this proposal. The undersigned Bidder further agrees to provide
all necessary machinery, tools, labor, and other means of construction; and to do all the work and to furnish all
materials, except as otherwise noted, necessary to perform and complete the said contract in accordance with the
2024 Standard Specifications for Roads and Structures by the dates(s) specified in the Project Special Provisions and
in accordance with the requirements of the Engineer, and at the unit or lump sum prices, as the case may be, for the
various items given on the sheets contained herein.
The Bidder shall provide and furnish all the materials, machinery, implements, appliances and tools, and perform the
work and required labor to construct and complete State Highway BID NO. 54-TJK-07-PR35943, for the unit or
lump sum prices, as the case may be, bid by the Bidder in his bid and according to the proposal, plans, and
specifications prepared by said Department, which proposal, plans, and specifications show the details covering this
project, and hereby become a part of this contract.
The published volume entitled North Carolina Department of Transportation, Raleigh, Standard Specifications for
Roads and Structures, January 2024 with all amendments and supplements thereto, is by reference incorporated into
and made a part of this contract; that, except as herein modified, all the construction and work included in this contract
is to be done in accordance with the specifications contained in said volume, and amendments and supplements
thereto, under the direction of the Engineer.
If the proposal is accepted and the award is made, the contract is valid only when signed either by the Contract Officer
or such other person as may be designated by the Secretary to sign for the Department of Transportation. The
conditions and provisions herein cannot be changed except over the signature of the said Contract Officer or Division
Engineer.
The quantities shown in the itemized proposal for the project are considered to be approximate only and are given as
the basis for comparison of bids. The Department of Transportation may increase or decrease the quantity of any
item or portion of the work as may be deemed necessary or expedient.
An increase or decrease in the quantity of an item will not be regarded as sufficient ground for an increase or decrease
in the unit prices, nor in the time allowed for the completion of the work, except as provided for the contract.

Bid No. 54-TJK-07-PR35943 3 Caswell County Janitorial
TABLE OF CONTENTS
PROJECT SPECIAL PROVISIONS PAGE NO.
Project 5
Scope of Contract 5
Mandatory Pre-Bid 5
Bid Questions 5
Small Business Enterprise (SBE) Contract 5
Prequalification 6
Contract Time and Completion Date 6
Alternate Bid Item for Reduced Staffing during Budget Restrictions 7
Performance Guarantee 7
Authority of the Engineer 7
Award of Contract 8
Insurance 8
Subletting of Contract 10
Performance of Work 10
Temporary Suspension of Work 10
Site Investigation and Representation 10
Contract Cancellation Policies 10
Legal Relations and Responsibility to Public 12
Custodial Operations and Maintenance of Rest Areas 12
Project Pre-Work Conference 14
Personnel Requirements 14
Supervisor 16
General Requirements 18
Safety and Accident Protection 18
Mandatory Wage Rate 19
Materials, Supplies and Equipment 19
Repairs 21
Cleaning Schedule 27
Routine Repairs 29
Emergency Janitorial Supply and Repair Parts List 30
Highway Refreshment Vending Facilities 34
Water System Maintenance 35
Maintenance of Grounds 36
Trash/Recycling Collection/Disposal 37
Cooperation Between Contractors 39
Damages 39
Department Responsibilities 39
Performance of Work 40
Standard Compensation Reductions for Rest Area Personnel,
41
Supplies and Procedures for each Rest Area Site
Daily Compensation Reductions for each Rest Area Site 43
Notification of Rest Area Contract Non-Compliance 44
Compensation 45
Basis of Payment 45
Non-Scheduled Work 46
Laws 46
Title VI and Nondiscrimination 49

Bid No. 54-TJK-07-PR35943 4 Caswell County Janitorial
PROJECT SPECIAL PROVISION FORMS PAGE NO.
Supervisor's Weekly Work Log 57
Supervisor's On-The-Job Training Record 58
Employee Monthly Work Log, Custodians and Supervisor 59
Employee Sign In / Sign Out Log 61
Rest Area Illegal Activity Log 62
Rest Area Water Reading Monthly Report 63
Rest Area Lighting Inspection Sheet 64
Rest Area Recycling Program Monthly Report 65
Rest Area Contract Maintenance Janitorial Supplies (Sample) 66
Rest Area Contract Maintenance Janitorial Supplies (Blank) 67
DBE-IS Form 68
Contractor National Criminal Background Check Certification 69
INSTRUCTIONS TO BIDDERS PAGE NO.
Bid Proposals 70
Preparation and Submission of Traditional Paper Bids 70
Opening of Bids 71
BID SUBMITTAL PACKAGE PAGE NO.
Cover Sheet 1
Contractor Bid Form 2
Contractor's Contact Information 3
Contractor's Operations Plan 4
Listing of MB & WB Subcontractors 5
Contractor's Work Experience and References 6
Mandatory Minimum Wage Rate Requirement 8
Execution of Bid 9
Bid Submittal Package Checklist 17

Bid No. 54-TJK-07-PR35943 5 Caswell County Janitorial
PROJECT SPECIAL PROVISIONS
PROJECT
Caswell County Rest Area/Visitor Information Center (single) on US 29 at the NC 700 Intersection, Exit 167, One
(1) Mile South of the NC/VA Stateline.
SCOPE OF CONTRACT
The North Carolina Department of Transportation (hereinafter referred to as "Department") is seeking the services
of a janitorial maintenance company to provide custodial operations and maintenance of rest area consisting of but
not limited to an efficient janitorial service including labor, supervision, equipment and supplies as specified herein.
The intent of these specifications and requirements is to state and define the terms and conditions under which the
Contractor shall provide the management, supervision, and manpower capable of performing work at the highest
standards of janitorial excellence necessary to provide these services in a professional and workmanlike manner.
This document is intended as a benchmark of the Department's minimum standards for rest area janitorial
maintenance.
The Department places significant value on the safety and treatment of travelers who visit rest areas. All travelers
are to be treated as customers and the Contractor shall emphasize safety and customer service at all times. The
provisions of the services required as part of this solicitation ultimately reflect upon the Department and the State of
North Carolina as a whole. This proposal, as written, is to be binding by the State and the Contractor.
MANDATORY PRE-BID
Please be advised that any references in the RFP to pre-bid language will not apply as a pre-bid will not be held for
this contract. If bidders have questions, they will be addressed in an addendum. The Bidder is encouraged to make
his/her own observations of the site to determine the items identified in this contract as the Contractor's
responsibility.
BID QUESTIONS
Purpose: Upon review of the bid documents, bidders may have questions to clarify or interpret the bid in order to
submit the best bid possible. To accommodate the Bid Questions process, bidders shall submit by email any such
questions no later than July 15, 2026 at 5:00 PM. A response to bidder questions will be in the form of an
addendum.
Instructions: Written questions shall be emailed to Teddy Kapera tjkapera@ncdot.gov by the date and time
specified above. Bidders will enter "54-TJK-07-PR35943 - Questions" as the subject for the email. Questions
received prior to the submission deadline date, the State's response, and any additional terms deemed necessary by
the State will be documented and included in an addendum to be posted on Connect NCDOT:
https://connect.ncdot.gov/letting/Pages/Roadside-Environmental.aspx and on the electronic Vendor Portal
(eVP), https://evp.nc.gov. No information, instruction or advice provided orally or informally by any State
personnel, whether made in response to a question or otherwise in connection with this RFP, shall be considered
authoritative or binding. Bidders shall be entitled to rely only on written material contained in an Addendum to this
RFP.
The Contractor must sign the addendum signature page(s) where indicated and the entire addendum should be
returned with the bid package. Please return the entire addendum, but failure to return the executed signature
page(s) of the addendum may result in disqualification of bid.
SMALL BUSINESS ENTERPRISE (SBE) CONTRACT
The Department of Transportation does not exclude any person from participation in, deny any person the benefits
of, or otherwise discriminate against anyone in connection with the award and performance of any contract covered
by this program on the basis of race, color, sex, political affiliation/influence, or national origin.

Bid No. 54-TJK-07-PR35943 6 Caswell County Janitorial
This is a SBE contract and to qualify for the NCDOT SBE Program a firm must have an annual gross income of
$1,500,000 or less, exclusive of materials. Only contractors currently certified as a SBE Contractor by the
NCDOT Office of Civil Rights SBE Program Manager and listed in the Directory of Transportation Firms at
bid opening will be eligible to bid on this project.
Prospective bidders who qualify for the SBE Program and are not currently certified should submit a
completed application packet to the SBE Program Manager prior to bid submittal to allow for review time.
Additional information on the program, including the application to become certified, may be obtained online at:
https://connect.ncdot.gov/business/SmallBusiness/Pages/default.aspx
Bidders must renew their SBE status and recertify each year. It is the bidder's responsibility to ensure that their
existing SBE status does not lapse prior to bid opening. Advance notification of pending renewal dates is not
guaranteed.
Per G.S. 136-28.10, a NC General Contractor's license may be waived for SBE contracts. For this project, the NC
General Contractor's license will be waived. Per G.S. 136-28.10, contract payment and performance bonds may be
waived. For this project, the contract payment and performance bonds will be waived. However, a performance
guarantee will be required.
INTERESTED PARTIES LIST NOT REQUIRED:
(6-21-22)(Rev. 2-20-24) 102 SP1 G02
Revise the Standard Specifications as follows:
The Interested Parties List sign up process is not applicable to this contract.
Page 1-13, Article 102-3 PROPOSALS AND INTERESTED PARTIES LIST, lines 12-15, delete the first
paragraph.
Page 1-14, Article 102-8 PREPARATION AND SUBMISSION OF BIDS, lines 43-44, delete the first sentence
of the first paragraph.
PREQUALIFICATION
The Department encourages and promotes the growth, development, and continuation of competent Contractors
that can perform the work necessary under this contract. The Department's procurement process is built on the
principle of competition. The Department believes that the specifications and requirements under this contract are
reasonable to satisfy the need for services requested, but are not unduly restrictive, in order to encourage
competition in the open market. In furtherance of these principles, bidders are not required to be prequalified for
this contract. All references to "prequalification" of bidders are hereby waived for this contract.
CONTRACT TIME AND COMPLETION DATE
The date of availability for this contract will be October 1, 2026. The completion date for this contract is one (1)
year from date of availability. This project is to be awarded, if the award is to be made in the discretion of the
Department, within thirty (30) days after the opening of bids.
Extension of Contract: At the sole option and discretion of the contracting agency, North Carolina Department of
Transportation (NCDOT), and upon written notification, this contract may be extended for two (2) additional
periods, one (1) year each, unless a shorter time is mutually agreed upon by the parties, (maximum of three years
total), to include leap year when applicable. Extensions for additional term(s) are not guaranteed. Upon receipt of
notification, the Contractor will be given fifteen (15) days to reply as to acceptance or rejection of an extension. If
a reply is not received from the Contractor within fifteen (15) days, NCDOT reserves the right not to extend. The
lump sum bid price will be increased for each one-year extension by two (2) percent of the current price. No
changes in the terms, conditions, etc. of this contract will be made when an extension to the contract is
implemented. The Contractor will be notified ninety (90) days before expiration of the contract if NCDOT chooses

Bid No. 54-TJK-07-PR35943 7 Caswell County Janitorial
not to offer an extension.
In accordance with G.S. 136-28.10 (Highway Fund and Highway Trust Fund Small Project Bidding) the maximum
contract limit for Small Business Enterprise (SBE) projects is $500,000 per year.
NOTE: In order to extend the contract, proof of insurance coverage must be received by the Department's
Purchasing Office, thirty (30) days prior to the expiration of the current contract.
SMALL BUSINESS ENTERPRISE (MULTI-YEAR MAINTENANCE CONTRACTS):
(4-20-21)(Rev. 4-19-22) SP1 G72
This contract is a multi-year contract let pursuant to the Small Business Enterprise provisions of N.C. General
Statute 136-28.10. In accordance with N.C. General Statute 136-28.10, an award in a contract may be for an
amount less but shall not exceed $1,000,000 per year. No payments in excess of this amount will be disbursed, in
accordance with the Statute.
ALTERNATE BID ITEM FOR REDUCED STAFFING DURING BUDGET RESTRICTIONS
In the event that budget restrictions are in effect at any time during the course of this contract, reduced staffing will
go into effect. Therefore, an alternate bid item for Reduced Staffing during Budget Restrictions is included in this
proposal and will be utilized during the restricted time as determined by the Engineer.
All applicable provisions included in this proposal shall be considered a part of this alternate bid item.
Bidders submitting only the lump sum bid price for Provide Custodial Operation and Maintenance and not the
alternate monthly bid price for Provide Custodial Operation and Maintenance with Reduced Staffing during Budget
Restrictions will be considered irregular and will result in rejection of bid.
Conversely, bidders submitting only the alternate monthly bid price for Provide Custodial Operation and
Maintenance with Reduced Staffing during Budget Restrictions and not the lump sum bid price for Provide
Custodial Operation and Maintenance be considered irregular and will result in rejection of bid.
Both bid items must be submitted, or the bid will be considered irregular and will result in rejection of bid.
For the sole purpose of determining the lowest cost, the Bidder's lump sum bid price for Provide Custodial
Operation and Maintenance will be used in the evaluation of the bid proposal. The alternate bid item for Provide
Custodial Operation and Maintenance with Reduced Staffing during Budget Restrictions must be a responsible bid
as well, or the Department reserves the right to negotiate the price prior to the budget restrictions taking effect.
PERFORMANCE GUARANTEE
For the first year of this contract, the Contractor agrees to a Performance Guarantee consisting of five (5)
per cent less than the amount of the monthly compensation. This is the amount of monthly compensation before
any non-compliance or performance deductions. The Performance Guarantee will not be deducted for extensions
and will be refunded without interest, pending the project site review, by the Contracting Agency at the end of the
initial contract unless an extension has been effected in which case the Performance Guarantee will be refunded at
the completion of the final contract extension. In cases of default, the Performance Guarantee will not be refunded
to the Contractor.
AUTHORITY OF THE ENGINEER
The Engineer for this project shall be the Division Engineer, Division Seven, Division of Highways, North Carolina
Department of Transportation, acting directly or through his duly authorized representatives. The Engineer will
decide all questions which may arise as to the quality and acceptability of work performed and as
to the rate of progress of the work; all questions which may arise as to the interpretation of the contract; and all
questions as to the acceptable fulfillment of the contract on the part of the Contractor. His decision shall be final

Bid No. 54-TJK-07-PR35943 8 Caswell County Janitorial
and he shall have executive authority to enforce and make effective such decisions and orders as the Contractor
fails to carry out promptly.
The published volume entitled North Carolina Department of Transportation, Raleigh, Standard
Specifications for Roads and Structures with all amendments and supplements thereto, is by reference
incorporated into and made a part of this contract. Unless otherwise modified, all the work included in this contract
is to be done in accordance with the specifications contained in said volume, and amendments and supplements
thereto, under the direction of the Engineer.
AWARD OF CONTRACT
"The North Carolina Department of Transportation, in accordance with the provisions of Title VI of the Civil
Rights Act of 1964 (78 Statue. 252) and the Regulations of the Department of Transportation (49 C.F.R., Part 21),
issued pursuant to such act, hereby notifies all bidders that it will affirmatively insure that the contract entered into
pursuant to this advertisement will be awarded to the lowest responsible bidder without discrimination on the
ground of race, color, or national origin".
All eligible proposals will be evaluated and acceptance made of the bid judged in the discretion of the contracting
agency to determine the lowest responsible bidder for the purpose intended. The Contracting Agency using its
discretion, will determine whether a bidder is a "responsible" bidder. In determining whether a bidder is
"responsible, the Contracting Agency will evaluate, the bid price, completeness and content of the bid, Bidder's
experience, ability of the Bidder and staff to perform the services required, Bidder's past performance, references,
operations plan including completed personnel and materials outlines, and Bidder's financial stability. After
opening bids and prior to award, the Contracting Agency may also seek additional information from any or all
bidders regarding the bidder's proposal, qualifications, experience, and ability to perform the required work prior to
determining whether a bidder is a "responsible" bidder. No changes in bid price or price negotiations will be
allowed after bids are opened and prior to an award. After the Contracting Agencies evaluation, the award of the
contract, if awarded, will be made to the lowest responsible bidder. The lowest responsible bidder will be notified
that his bid has been accepted and that he has been awarded the contract. If a Bidder is awarded a contract, he/she
will be expected to perform the work. Failure to perform may result in the Bidder being held in default of contract.
In the event of default, the Department may, in its discretion, contact the next lowest responsible bidder to
determine whether that next lowest responsible bidder is willing and able to complete the contract at its bid price.
Unless otherwise allowed by the Engineer, any formal protest to any proposed bid shall be made in writing (email
is acceptable) to the Engineer for the project within five (5) days of bid opening and shall clearly indicate that it is a
"bid protest." The protest must list each item that the protester believes is grounds for rendering a bid defective.
The Engineer will evaluate the protest and determine, in his/her discretion, whether any further action should be
taken. Further action may consist of, but not limited to, seeking additional information and/or clarification from
any and all bidders regarding the alleged complaint/protest, rejecting any or all bids, finding any or all bids
irregular, finding any or all bidders "not responsible", holding a possible informal meeting to discuss the protest, or
other actions in the discretion of the Engineer. After further evaluation the Engineer will notify the protesting party
what further action, if any, will be taken with regard to the protest. All awards are final and are not subject to
further review.
INSURANCE
The Contractor shall be liable for any losses resulting from a breach of the terms of this contract. The Contractor
shall be liable for any losses due to the negligence or willful misconduct of its agents, assigns and employees including
any sub-contractors which causes damage to others for which the Department is found liable under the Torts Claims
Act, or in the General Courts of Justice, provided the Department provides prompt notice to the Contractor and that
the Contractor has an opportunity to defend against such claims. The Contractor shall not be responsible for punitive
damages.
The Contractor shall at its sole cost and expense obtain and furnish to the Department an original standard Association
for Cooperative Operations Research and Development (ACORD) certificate of liability insurance evidencing
commercial general liability with a limit for bodily injury and property damage in the amount of $5,000,000 per

Bid No. 54-TJK-07-PR35943 9 Caswell County Janitorial
occurrence and $5,000,000 general aggregate, covering the Contractor from claims or damages for bodily injury,
personal injury, or for property damages that may arise from operating under the contract by the employees and
agents of the Contractor. The required limit of insurance may be obtained by a single general liability policy or the
combination of a general liability and excess liability or umbrella policy. The State of North Carolina shall be named
as an additional insured on this commercial general liability policy. The policy may contain the following language
as relates to the State as an additional insured: "This insurance with respect to the additional insured applies only to
the extent that the additional insured is held liable for your or your agent's acts or omissions arising out of and in the
course of operations performed for the additional insured."
The Contractor shall maintain all legally required insurance coverage, including without limitation, worker's
compensation and vehicle liability, in the amounts required by law. Providing and maintaining adequate insurance
coverage is a material obligation of the contractor and is of the essence of this contract. All such insurance shall meet
all laws of the State of North Carolina. Such insurance coverage shall be obtained from companies that are authorized
to provide such coverage and that are authorized by the Commissioner of Insurance to do business in North Carolina.
The Contractor shall at all times comply with the terms of such insurance policies.
Upon execution of the contract, provide evidence of the above insurance requirements to the Engineer. Insurance
coverage shall be maintained during the life of this contract and shall extend to operations performed by the contractor
or his subcontractors, and by anyone employed directly or indirectly by either of them.
The Contractor shall take out and maintain during the life of this contract Worker's Compensation Insurance for all
of his employees employed at the site(s) of the project, in the amounts required by law. In case any work is sublet,
the Contractor shall require the Subcontractor similarly to provide Worker's Compensation Insurance for all the
latter's employees employed at the site(s) of the project, unless such employees are covered by the protection
afforded by the Contractor.
Pursuant to N.C.G.S. 97-19, all contractors of the Department of Transportation are required, prior to beginning
services, to show proof of coverage issued by a workers' compensation insurance carrier, or a certificate of
compliance issued by the Department of Insurance for self-insured subcontractors stating that it has complied with
N.C.G.S. 97-93.
The contractor shall defend, indemnify and hold harmless the North Carolina Department of Transportation, its
officers and employees from any claim, demand, suit, liability, judgment and expense (including attorney's fees and
other costs of litigation) arising out of or relating to injury, disease, or death of persons or damage to or loss of
property resulting from or in connection with the negligent performance of this contract by the contractor, its
agents, employees, and subcontractors or any one for whom the contractor may be responsible. The obligations,
indemnities and liabilities assumed by the contractor under this paragraph shall not extend to any liability caused by
the negligence of the Department of Transportation or its employees. The contractor's liability shall not be limited
by any provisions or limits of insurance set forth in this contract.
The Contractor shall take out and maintain during the life of this contract such Public Liability and Property
Damage Insurance as shall protect him and Subcontractors performing work covered by this contract from claims
for damage or property damages which may arise from operations under this contract. This insurance shall protect
the Contractor whether such operations are done by himself or by any Subcontractor, or by anyone directly or
indirectly employed by either of them.
The Contractor shall at all times comply with the terms of such insurance policies, and all requirements of the
insurer under any such insurance policies, except as they may conflict with existing North Carolina laws or this
contract. The limits of coverage under each insurance policy maintained by the Contractor shall not be interpreted
as limiting the Contractor's liability and obligations under the contract.
Proof of insurance from the Insurance Company as described above, for the period of the contract, shall be
furnished to the Engineer prior to beginning of service. In addition to proof of insurance, the Contractor's policy
shall include provisions whereby the Insurance Company will notify NCDOT thirty (30) days prior to the policy
being cancelled.

Bid No. 54-TJK-07-PR35943 10 Caswell County Janitorial
SUBLETTING OF CONTRACT
All work as outlined under this contract shall be performed by employees of the Contractor or by an approved
Subcontractor. Any requests for subcontracting must be submitted in writing to the Engineer a minimum of thirty
(30) days prior to the proposed implementation of the subcontract. Subcontracting of required personnel staffing
(including supervisor) will not be permitted in this contract. The approval of any subcontract will not release the
Contractor of liability under the contract, nor will the subcontractor or the second tier subcontractor have any claim
against NCDOT by reason of the approval of the subcontract.
Failure of the Contractor to comply with any of the provisions of this article may be justification for disqualifying
the Contractor from further bidding. Subletting of this contract or any portion of the contract shall conform to the
requirements of Article of 108-6 of the Standard Specifications.
PERFORMANCE OF WORK
The Contractor's attention is directed to the need for the timely performance of services provided for under this
contract. The aesthetic appearance of the site and its reflection on the North Carolina Department of Transportation
as well as the safety and convenience of the public is the essence of the service.
TEMPORARY SUSPENSION OF THE WORK
The Engineer or his representative will observe operations and may suspend work for unsafe activities or
conditions. Work will not resume until the unsafe condition has been eliminated or corrected.
Failure to comply with any of the requirements for safety and traffic control of this contract shall result in
suspension of work as provided in Article 108-7 of the Standard Specifications.
SITE INVESTIGATION AND REPRESENTATION:
By signing the proposal documents, the Contractor acknowledges that:
(A) He understands the nature of the work and general and local conditions, particularly those bearing on
transportation;
(B) He is familiar with the availability and cost of labor and materials;
(C) He will to adhere to State regulations for safety and security of property, roads, and facilities;
(D) He is able to prosecute the work in accordance with all applicable local, state and federal rules and
regulations, and;
(E) He has thoroughly investigated the project site(s).
Any failure on the part of the Contractor to acquaint himself with all available information shall not relieve him from
the responsibility of any aspect of the contracting process. No adjustment in contract time or contract prices will be
made due to the Contractor's negligence to familiarize himself with the contract or project site(s).
CONTRACT CANCELLATION POLICIES
The Department of Transportation shall have the right to declare default of contract for breach by the Contractor of
any material term or condition of the contract. Default of contract shall be in accordance with the terms,
conditions, and procedures of Article 108-9 of the Standard Specifications.
CANCELLATION BY DEPARTMENT (DEFAULT)
The general reputation and performance of the Contractor is a reflection on the Department of Transportation. This
contract may be cancelled at any time by reason of unsatisfactory performance or other default of the Contractor
upon five (5) day's prior written notice by the Department. In addition, this contract may be cancelled immediately
by written notification upon receipt of substantiated notification and verification that the Contractor has failed to