Engineering Services Master Agreement for Smith-Reynolds Airport

Location:	North Carolina
Posted:	Sep 1, 2026
Due:	Oct 2, 2026
Agency:	State Government of North Carolina
Type of Government:	State & Local
Category:	C - Architect and Engineering Services - Construction R - Professional, Administrative and Management Support Services
Solicitation No:	281-RFQ2749
Publication URL:	To access bid details, please log in.

Solicitation Number:	281-RFQ2749
Project Title:	Engineering Services Master Agreement for Smith-Reynolds Airport
Description:	Forsyth County proposes to engage the services of qualified engineering firms to provide planning, design, construction, and consulting services for various airport-related projects at the Smith Reynolds Airport. The resulting contract will be a 5-year master agreement where fees will be negotiated on an individual project basis once the project scope is confirmed.
Opening Date:	10/2/2026 4:00 PM
Posted Date:	9/2/2026
Status:	Open
Department:	CITY OF WINSTON-SALEM


Solicitation Number * 281-RFQ2749	Department CITY OF WINSTON-SALEM	Status Reason Open
Opening Date 2026-10-02T16:00:00.0000000	Posted Date * 2026-09-01T19:13:56.0000000Z	Primary Commodity Code Civil engineering
Mandatory Conference/Site Visit — —	Special Instructions Contact: darrenmr@cityofws.org	Solicitation Type * RFP
Owner Russell Frye
Description Forsyth County proposes to engage the services of qualified engineering firms to provide planning, design, construction, and consulting services for various airport-related projects at the Smith Reynolds Airport. The resulting contract will be a 5-year master agreement where fees will be negotiated on an individual project basis once the project scope is confirmed.

Attachment Preview

REQUEST FOR QUALIFICATIONS

ENGINEERING SERVICES MASTER AGREEMENT

FOR AIRPORT PLANNING AND DESIGN

SMITH REYNOLDS AIRPORT, WINSTON-SALEM, NORTH CAROLINA

RFQ2749

issue date 09.01.26

Proposals shall be complete and comply with the requirements listed herein.

Submit Proposals electronically by 4:00 pm, October 2, 2026 to the attention of Mark R.

Davidson, A.A.E. at mark.davidson@smithreynolds.org Responses received after this

date and time will be deemed non-responsive and will not be considered.

Questions are to be directed to Darren Redfield at darrenmr@cityofws.org and Russell Frye

russellf@cityofws.org by the End of Question deadline of 4:00 pm, September 16, 2026.

Summary: Forsyth County proposes to engage the services of qualified engineering firms to provide

planning, design, construction, and consulting services for various airport-related projects at the Smith

Reynolds Airport. The resulting contract will be a 5-year master agreement where fees will be

negotiated on an individual project basis once the project scope is confirmed. The County reserves

the right to contract with up to two firms under a master agreement.

This document is the full Request for Qualifications.

Page 1 of 5

NOTICE TO PROPOSERS

The following references serve as the procedures, requirements and guidance for staff under this

RFQ and any resulting contracts: FAA AC 150/5100-14E, FAA Order 5100.38D, 48 CFR Part 31, Title

2 CFR Part 200, North Carolina Program Guidance Handbook, and NCGS 143-64-31 “Mini-Brooks

Act”.

This Request for Qualifications (RFQ) will in no manner be construed as a commitment on the part of

the County to award a contract. The County reserves the right to reject any or all applications; to

waive minor irregularities in the RFQ process or in the applications; to re-advertise this RFQ; to

postpone or cancel this process; select and procure parts of services; and to change or modify the

RFQ schedule at any time.

It is the policy of the County of Forsyth that an employee, officer, or agent of the County may not

participate in any manner in the bidding, awarding, or administering of contracts or agreements in

which they, or a member of their immediate family, their business partner, or any organization in

which they serve as an officer, director, trustee, or employee, have a financial interest.

Successful Proposers must comply with all provisions of the Americans with Disabilities Act (ADA)

and all rules and regulations promulgated thereunder. By submitting a proposal, the successful

Proposers agrees to indemnify the County from and against all claims, suits, damages, costs, losses,

and expenses in any manner arising out of, or connected with, the failure of the Company, its

subcontractors, agents, successors, assigns, officers, or employees to comply with the provisions of

the ADA or the rules and regulations promulgated thereunder.

All proposals must be firm and not subject to increase, unless specified within the provisions of this

Request for Qualifications (RFQ) and mutually agreed upon by the County and the Proposer. No

special inducements will be considered that are not a part of the original proposal document.

County Rights and Options

The County, at its sole discretion, reserves the following rights:

● To supplement, amend, substitute or otherwise modify this RFQ at any time

● To cancel this RFQ with or without the substitution of another RFQ

● To take any action affecting this RFQ, this RFQ process, or the services subject to this RFQ that

would be in the best interests of the County

● To issue additional requests for information or clarification from proposers or to allow corrections of

errors or omissions

● To require one or more Service Providers to supplement, clarify or provide additional information in

order for the County to evaluate the Responses submitted

● To negotiate an agreement with one or more Service Providers based on the information provided

in response to this RFQ.

● This RFQ does not obligate Forsyth County to contract for services specified herein.

Public Records

Any material submitted in response to this RFQ will become a “public record” once the Proposer’s

document(s) is opened and the Proposer is determined to be a participant in the solicitation process

and shall be subject to public disclosure consistent with Chapter 132, North Carolina Statutes.

Proposers must claim any applicable exemptions to disclosure provided by law in their response to

this RFQ. Proposers must identify materials to be protected, and must state the reasons why such

exclusion from public disclosure is necessary and legal. The County reserves the right to make all

final determination(s) of the applicability of North Carolina General Statutes § 132-1.2, Confidential

Information.

Trade Secrets/Confidentiality

Page 2 of 5

Proposers must claim any material that qualifies as "trade secret" information under N.C.G.S. 66-

152(3) in their response to this RFQ and must state the reasons why such exclusion from public

disclosure is necessary and legal.

To properly designate material as trade secret under these circumstances, each Proposer must take

the following precautions: (a) any trade secrets submitted by a Proposer should be submitted in a

separate, sealed envelope marked "Trade Secret - Confidential and Proprietary Information - Do Not

Disclose Except for the Purpose of Evaluating this Proposal," and (b) the same trade

secret/confidentiality designation should be stamped on each page of the trade secret materials

contained in the envelope.

Do not attempt to designate your entire proposal as a trade secret, and do not attempt to

designate pricing information as a trade secret. Doing so may result in your proposal being

disqualified.

In submitting a proposal, each Proposer agrees that the County may reveal any trade secret materials

contained in such response to all County staff and City/County officials involved in the selection.

Familiarity with Laws and Ordinances

The submission of a proposal on the equipment requested herein shall be considered as a

representation that the Proposer is familiar with all federal, state, and local laws, ordinances, rules

and regulations which affect those engaged or employed in the provision of such services, or

equipment used in the provision of such services, or which in any way affects the conduct of the

provision of such services; and no plea of misunderstanding will be considered on account of

ignorance thereof. If the Proposer discovers any provisions in the RFQ documents that are contrary to

or inconsistent with any law, ordinance, or regulation, it shall be reported to the County in writing

without delay.

E-Verify Compliance

Per N.C.G.S. 143-133.3, provider shall comply with the requirements of Article 2 of Chapter 64 of the

North Carolina General Statutes. Further, if the Provider utilizes a subcontractor, the Provider shall

require the subcontractor to comply with the requirements of Article 2 of Chapter 64 of the North

Carolina General Statutes.

Iran Divestment Act

Provider hereby certifies that it is not on the North Carolina State Treasurer’s list of persons engaging

in business activities in Iran, prepared pursuant to NCGS 147-86.58, nor will Provider utilize on this

agreement any subcontractor on such list.

Divestment from Companies that Boycott Israel

Contractor hereby certifies that it is not on the North Carolina State Treasurer’s list of companies

engaged in a boycott of Israel in violation of NCGS 147-86.80 et. seq. and that it will not utilize on this

agreement any subcontractor on said list.

Page 3 of 5

INFORMATION AND REQUIREMENTS

1. Location of Project:

Smith Reynolds Airport

3801 N. Liberty Street

Winston-Salem, NC 27105

2. Description of Project:

Forsyth County plans to contract for engineering services with one or more firms for a period of

five years from the time of the contract signing and retains the right to add to or delete from the

projects listed in the Scope of Services. Fees will be negotiated with the selected engineering firm

for each individual project.

3. Scope of services:

Forsyth County proposes to engage the services of qualified engineering firms to provide

planning, design, construction, and consulting services for various airport related projects at the

Smith Reynolds Airport. These projects may include, but are not limited to runway

strengthening/overlay, environmental studies, master planning, ALP update, airfield lighting,

signage, NAVAIDS, taxiways, taxilanes and apron extensions/rehabilitations, safety area

improvements, obstruction removal, land acquisition, automobile parking lot improvements, airfield

drainage, Engineering Material Arresting System (EMAS) rehabilitation/replacement, industrial

development, hangar construction, support building construction, building systems, terminal

improvements, noise barrier, perimeter fencing, security improvements, fuel farms, utility

infrastructure development and upgrades, landside access improvements, and other similar airport

related projects.

4. Selection Criteria:

Interested firms should submit their letter of interest addressing the following criteria:

A. Familiarity with the airport by firm’s project manager.

B. Capability to perform all aspects of the project, including planning, design, and construction

phase services.

C. Experience level of the firm’s project manager and aviation staff.

D. Working relationship with the North Carolina Department of Transportation - Division of

Aviation and the Federal Aviation Administration.

E. Current workload and capacity to meet schedules.

F. Demonstrated ability to effectively manage and administer federal and state aviation grants,

including grant application preparation, coordinating with funding agencies, compliance

requirements, reimbursement requests, closeout, and ongoing grant administration.

G. Evidence of minimum insurance limits:

$5M Professional Liability

$1M Commercial General Liability

$1M Business Automobile Liability

Workers Compensation: NC statutory limits and not less than $100,000 each accident.

5. Selection Process:

The submittal shall be Selection will be made from the information submitted unless an interview is

requested by the selection committee. One or more firms will be selected by a committee in fair

and uniform manner based in part on appropriate qualifications, experience for this type of work,

and current workload. The selection committee is comprised of Airport staff, Airport Board, and

Forsyth County Construction Management staff. Upon receipt of the proposals from respondents,

the committee members will review the proposals in detail, make its selection, and provide written

recommendation to the County Manager for his approval. If the County Manager’s agrees with the

recommendation, the Manager and Airport Director will request approval from the Forsyth County

Commissioners. Following approval from the Board of County Commissioners, the contract terms

Page 4 of 5

and conditions will be negotiated with the selected firm. In the event contract negotiations prove

unsuccessful with the selected firm, the committee will select another firm with which to begin

negotiations.

6. Schedule:

The key activities and milestone dates for the selection process are listed below:

Activity

Addendum to respond to questions

Proposal submission deadline

Selection Committee meeting to review

Board of Commissioners briefing

Board of Commissioners award meeting

Firm(s) selection notification

Contracts finalized and begin work

Milestone Date

09/25/26

10/02/26

10/16/26

11/09/26

11/12/26

11/16/26

02/01/26

7. RFQ Responses should include the following:

A. Letter of interest

B. Firm history

C. Current project list of proposed Project Manager/team. Include current stage of the project and

projected completion date.

D. List previous projects of similar scope to a maximum of ten projects.

E. Resumes for staff who would be assigned to the project.

F. List of proposed sub-consultants.

8. RFQ Submission Response Format and:

Limit proposals to a maximum of twenty (20) total 8.5” x 11” pages (single side). Proposals shall

be submitted electronically in PDF format by the deadline and to the person noted on page 1. All

responses must be signed by an official agent or representative of the company submitting the

response. Responses received after this date and time will be deemed non-responsive and will not

be considered.

9. General Comments:

• Any cost incurred by respondents in preparing or submitting a response for the project shall be

the respondents’ sole responsibility.

• All responses, inquires or correspondence relating to this RFQ will become the property of

Forsyth County when received.

• Respondents are to refrain from contact with the selection committee members. Any

questions regarding the RFQ should be submitted by email and directed to Darren Redfield at

darrenmr@cityofws.org. If a question of general concern is asked by any firm with regards to

this RFQ, a copy of the written response will be issued by addendum. The deadline for

inquires is noted on page 1.

• Forsyth County has the sole discretion and reserves the right to reject any and all responses

received with respect to this RFQ and to cancel the process at any time prior to entering into a

formal agreement. The County reserves the right to request additional information or

clarification of the information provided in the response without changing the terms of the

RFQ.

10. Confidentiality of Documents:

In general, documents that are submitted as part of the response to this RFQ will become public

records, and will be subject to public disclosure. North Carolina General Statutes Section 132- 1.2

and 66-152 provide a method for protecting some documents from public disclosure. See page 2

for detailed information.

Page 5 of 5

This is the opportunity summary page. It provides an overview of this opportunity and a preview of the attached documentation.

Daily notification on new contract opportunities

With GovernmentContracts, you can:

Find more opportunities and win more business
Receive daily alerts for all new bid opportunities
Get contract opportunities matched to your business

ONE WEEK FREE TRIAL

Engineering Services Master Agreement for Smith-Reynolds Airport

Attachment Preview

See also