27-1112 Metal Roof & Siding Replacement, Cataldo Office

Location:	Idaho
Posted:	Jun 17, 2026
Due:	Jul 28, 2026
Agency:	Idaho Department of Lands
Type of Government:	State & Local
Category:	Z - Maintenance, Repair or Alteration of Real Property
Publication URL:	To access bid details, please log in.

Attachment Preview

STATE OF IDAHO

DEPARTMENT OF LANDS

ROOF & SIDING REPLACEMENT – METAL STORAGE BUILDING

CATALDO FOREST PROTECTION DISTRICT

REQUEST FOR QUOTE NO. 27-1112

DUE BEFORE 2:00:00 P.M. P.T. on JULY 28, 2026

REQUEST FOR QUOTE

AND

INSTRUCTIONS

Quotes will be received by the Idaho Department of Lands for the following:

ROOF & SIDING REPLACEMENT – METAL STORAGE BUILDING

CATALDO FOREST PROTECTION DISTRICT

DELIVERY LOCATION:

Idaho Department of Lands

80 Hilltop Overpass Rd.

Kingston, ID 83839

INSTRUCTIONS:

The purpose of this Request for Quote (RFQ) package is to solicit quotes for Roof & Siding

Replacement – Metal Storage Building outlined in the attached Schedule A and Project

Description. All price quotes must be entered on the attached Schedule A. The signed Schedule

A shall be Electronically Submitted to the email listed below. Idaho Department of Lands will

award a contract to the qualified vendor submitting the lowest responsible and responsive quote.

The TOTAL PRICE will be the basis for award. The Quotation must be in U.S. Dollars.

Idaho Department of Lands reserves the right to enter negotiations in accordance with IDL

Procurement Policy #455. Cataldo FPD,

SITE VISIT:

A pre-bid site visit will be held at 9:00 AM P.T. on Thursday, July 16, 2026, at Cataldo FPD, 80

Hilltop Overpass Rd., Kingston, ID 83839. While attendance is not mandatory, interested

vendors are encouraged to attend and participate. All measurements included in this document

are approximations and a site visit is recommended to verify distances are accurate dimensions

needed for quoting.

QUOTES DEADLINE AND ELECTRONIC DELIVERY REQUIREMENTS:

Quotes must be received before 2:00:00 P.M. P.T. on July 28, 2026. IDL is not responsible for

delayed delivery of electronically submitted quotes. The date and time of electronically received

quotes, to the IDL email address listed below, will be used to determine if electronically

submitted quotes were received by the due date and time specified. If you are not able

electronically transmit your quote by email you must call 208.666.8613 and your quote will be

recorded over the phone. Late Quotes will not be accepted. Fax Quotes will not be accepted.

Mailed Quotes will not be accepted

Quote Email Address:

mrsande@idl.idaho.gov

QUESTIONS:

Questions pertaining to this RFQ must be submitted in writing by email to

mrsande@idl.idaho.gov. The deadline for receiving questions is 12:00:00 P.M., on 7/20/2026.

Responses to all questions received will be posted as an addendum on the IDL website at

www.idl.idaho.gov. Verbal questions will not be accepted.

You must be registered in LUMA and PaymentWorks to receive a contract.

The successful responsive contractor will have 10 days from

notice of award to be registered.

IDL RFQ 27-1112

Page 2 of 10

Roof & Siding Replacement -

Metal Storage Building - Cataldo

INSTRUCTIONS:

SCHEDULE A

STATE OF IDAHO

DEPARTMENT OF LANDS

REQUEST FOR QUOTE

THIS IS NOT AN ORDER

Requisition Number: 27-1112

• Responders must use this form in submitting prices.

• All bids over $50,000.00 require a Public Works License.

• All permits will be the responsibility of the Contractor; any permit fees will be paid for by the

Contractor and should be included in the Contractor’s quote.

• All measurements included in this document are approximations and a site visit is recommended

to verify distances are accurate dimensions needed for quoting.

• Project Site Address: 80 Hilltop Overpass Rd, Kingston, ID 83839

QUAN. UNIT

ARTICLES

LS Remove and Replace Roof and Siding per

Attached Scope of Work

UNIT PRICE TOTAL PRICE

Action

Request for Quote Responses Due Before:

Project must be completed by:

Due Date

2:00:00 P.M. P.T. 7/28/2026

11/1/2026

If your informal bid is over $50,000.00, you must include your active Idaho Public Works

Contractor License Number here: _____________. A copy of license must me submitted with

Schedule A.

SUBMISSION DELIVERY:

EMAIL QUOTE TO: mrsande@idl.idaho.gov

We have stated hereon the prices at which we will furnish and at destination named above, the articles

or services as specified. Delivery will be made as specified above.

Firm ______________________________________________

Street _____________________________________________

City

State

Zip Code ________

Phone

Fax __________________

Email ____________________________________________

Signed by _________________________________________

Printed Name ______________________________________

Title ______________________________________________

Date __________________

IDL RFQ 27-1112

Page 3 of 10

Roof & Siding Replacement -

Metal Storage Building - Cataldo

IDL PROJECT #27-1112

SCOPE OF WORK

PROJECT NAME: ROOF & SIDING REPLACEMENT – METAL STORAGE BUILDING

PROJECT COMPLETION DATE: 11/1/2026

PROJECT LOCATION:

Cataldo Forest Protection District

80 Hilltop Overpass Rd., Kingston, ID 83839

WORK TO BE PERFORMED:

Project shall include the demolition, removal and disposal of existing metal roofing,

siding, and associated trim on 125’ x 30’ metal building. The existing siding, roof, and

trim will be replaced with 24-gauge Glacier White Purlin Bearing Rib (PBR) roofing,

Ivory colored 26-gauge high tensile steel siding, associated trim to include ridge cap,

drip cap, corner caps, beam and door wraps. Additionally, vendor will install 2”

insulation blanket on enclosed portion of the building (approximately 50’x30’ exterior

dimension), approximately 50’ of rain gutters, 4 downspouts, 100’ of snow breaks as

directed by the COR, and an owner provided exterior light (owner provided exterior

light will replace existing exterior light). Roof and siding fasteners must be #14

minimum size.

Minimum 7-year warranty on materials and workmanship.

Contractor to provide any and all necessary permits.

All bids over $50,000 must include a copy of the vendor’s public works license

for the State of Idaho submitted with the Schedule A.

Note:

1. Exterior dimension of the building is approximately 125’ x 30’.

2. Roof pitch is approximately 3:12.

3. Eve of building is approximately 11’ above ground level.

4. Peak of building is approximately 13’6” above ground level.

5. Existing sliding door and awning on west side of building will be removed by the

owner and metal siding installed in its place.

PROJECT REQUIREMENTS:

1. Contractor will ensure they meet any and all State trade licensing requirements.

All work to be completed will meet all applicable State and Federal laws.

IDL RFQ 27-1112

Page 4 of 10

Roof & Siding Replacement -

Metal Storage Building - Cataldo

2. Contractor shall be responsible for all permits and permit fees.

3. Contractor will remove and dispose of existing materials that are to be replaced.

4. Contractor will provide new materials unless specifically stated that the owner

will provide materials to be installed.

5. All materials must be installed in accordance with manufacturer’s specifications.

6. Contractor is responsible for verifying the accuracy of all measurements.

7. Contractor will protect building and landscape and leave the premises in a clean

and debris free condition.

SAFETY:

Contractor shall comply with all applicable local, state, and federal safety regulations

including:

Federal Occupational Safety and Health Administration (OSHA) Standards.

The Contractor will be solely responsible for safety at the site.

PROJECT PERIOD AND SCHEDULE:

Contract work may commence after the Contractor received a Notice to Proceed and

has had a prework conference with the Contracting Officer Representative “COR”. All

work must be completed by 11/1/2026 in compliance with all Contract terms, clauses,

and associated special provisions (if applicable).

INSPECTION AND ACCEPTANCE: IDL COR will complete inspection report to include

with invoice for payment.

PAYMENT:

Invoices must be sent to Invoicing@idl.idaho.gov and cc’d to

dreeves@idl.idaho.gov . Invoices that are not sent to this address may be

delayed in processing and payment. Invoices must include the Contract

Number and a unique invoice number to prevent delays in processing.

Payment will be made to the Contractor upon satisfactory completion of fieldwork at the

rates set forth in Schedule A. Invoices must be itemized per the attached Schedule A;

payment will be made after receipt of the contractor’s itemized invoice for satisfactorily

completed work. Invoices shall be submitted no more than monthly and will include a

description of services completed during the period being invoiced. Per Idaho Code 67-

2302 (2) IDL has up to 60 days from receipt of an invoice for processing and payment.

IDL RFQ 27-1112

Page 5 of 10

Roof & Siding Replacement -

Metal Storage Building - Cataldo

This is the opportunity summary page. It provides an overview of this opportunity and a preview of the attached documentation.

27-1112 Metal Roof & Siding Replacement, Cataldo Office - due July 28, 2026

Attachment Preview

See also