Raleigh Police Department Evidence Facility

ADVERTISEMENT FOR PRE-
QUALIFICATIONS POSTED: 7/15/2026
CITY BID NUMBER: 274-FY2027-CM-PSSP03
Project: Raleigh Police Department Evidence Facility
Owner: City of Raleigh, North Carolina, Engineering Services Department,
One Exchange Plaza, Suite 620, Raleigh, NC 27601.
Construction Manager: Consigli Construction, 4819 Emperor Blvd. Suite 130 Durham, NC
27703
Contact: Manasa Badri, MBadri@consigli.com
Architect: Becker Morgan Group
Pursuant to NC statutes G.S. 143-128.1, Consigli has been selected as the CM at Risk and is
seeking to prequalify trade partners for the Raleigh Police Department Evidence Facility project.
A non-mandatory information session will be held at 10:00AM Tuesday, July 21, 2026 at 2320
Law Enforcement Drive, Raleigh, NC 27610 in room 140.
A non-mandatory virtual information session will be held at 10:00AM Tuesday, July 28, 2026. For
session link, please contact Manasa Badri.
The Project is located at 8120 Battle Bridge Road Raleigh, NC 27610. The project consists
generally of the following major items:
One ground up 26,000 SF load bearing masonry structure, one 24,000 SF Pre-Engineered
Metal Building, finishes, sitework/utilities & exterior improvements. The following bid
packages are expected:
01 General Trades, 03 Concrete, 04 Masonry. Structural Steel & Misc. Metals, 06 Millwork,
07A Roofing, 07B Waterproofing & Joint Sealants, BP08A Doors Frames & Hardware,
08B Glass & Glazing, 08C Overhead Doors, BP 09A Drywall, BP 09B Acoustic Ceilings,
BP 09C Flooring, BP 09D Painting & Coatings, BP 10A Specialties, BP 10B Wire Mesh
Partitions, BP 10C Storage Shelving, BP 11A Equipment, BP 12A Furnishings, 13A Pre
Engineered Metal Building, 13B Cold Storage, 21A Fire Protection, 22A Plumbing, 23A
HVAC, 23B Geothermal Wells, 26A Electrical & Low Voltage, 31A Sitework & Utilities. See
pre-qualification form for further information.
Pre-qualification forms are due August 6, 2026 at 5:00PM to Manasa Badri by email at
MBadri@consigli.com. Late forms will not be accepted. Pre-qualification forms and additional
information are included in this advertisement and may also be obtained by contacting Manasa
Badri at 4819 Emperor Blvd. Suite 130 Durham, NC 27703 or by email at MBadri@consigli.com
City of Raleigh
Janet Cowell, Mayor
END OF DOCUMENT
City of Raleigh 00100-1 Advertisement for Pre-Qualifications

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
Pursuant to the statute, this form gathers information about the subcontractors seeking to
qualify for the work and provides a general format for the prequalification criteria. Completing
this questionnaire does not guarantee prequalification. Evaluation of the submittal shall be
performed by the prequalification committee in accordance with GS 143-128.1, 143-135.8 and
the City of Raleigh Prequalification Policy.
Subcontractors must use this project-specific form from the Prequalification Committee. Do
not use a blank template from the North Carolina State Construction Office website or any other
template previously used.
PREQUALIFICATION DUE DATE/TIME: August 6, 2026 5:00 pm.
(date) (time)
Submit to: Consigli Construction Company
Project:
Name of Project: RPD Evidence Facility
Project Owner: City of Raleigh
Project Architect: Becker Morgan Group
Project Start Date (Approx.): 4th Quarter 2026
Project/Phase Duration: 18 Months
Anticipated Bid Date: September 2026
Project Description:
The Evidence facility consists of 2 ground up structures. The main building is load bearing
masonry with brick facade, with administrative office areas and secured storage areas
throughout. The second building is an enclosed PEMB with SOG for auto storage. Site to include
geothermal wells, retaining walls, utilities and underground storm detention.
Anticipated Start of Construction: November 2026
Submittals: Interested Firms must submit one (1) hard copies of this form and all required
attachments. Late submittals will not be accepted.
City of Raleigh Prequalification Policy: Please note that the City's prequalification policy has been
included in this document as Appendix C. First tier subcontractors unable to meet bonding
requirements shall be ineligible for further consideration in the prequalification process. If the
notary certification of this form is incomplete, the form is invalid.
If your firm is interested in prequalifying for this project, please complete the following
document and submit as requested.
July, 2026 Page 1 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
SECTION 1. GENERAL COMPANY INFORMATION
1. a. Primary/Main office location:
Company Name:
Physical Address:
Mailing Address
City, State, and Zip Code
Phone number Fax number
Primary Contact Name Secondary Contact Name
Primary Contact Email Address Secondary Contact Email Address
Organization:
1. b. Business type (check box)
Corporation Partnership Limited Liability Company Sole Proprietor
Joint Venture
Is your firm registered with the State of North Carolina to do business?
Yes No
Is your firm owned or controlled by a parent or any other organization?
Yes No
Describe Ownership if Yes:
July, 2026 Page 2 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
List all other names your firm has operated as for the past five (5) years:
List owners, officers, partners, or individuals authorized to represent or conduct business for or sign legal
documents for the firm. This list must include the full legal name, typed or printed in a clear legible form.
[Note that firms experiencing changes in ownership, organizational structure, or material changes in
assets must inform the Bid Agent prior to the award of a contract. Failure of the firm to comply with this
requirement may result in the termination of any contract awarded by the City.]
1. c. Licensing Information (The Applicant must provide a copy of their North Carolina Contractor's
License)
Name of licensee/NC License number:
License Limit / Level:
State / County / City Privilege License:
Has any license ever been denied or revoked?
Yes No
If yes, please describe. Attach additional sheets as needed.
1. d. Type of Work Performed on a regular basis
Primary Scope of Work:
Secondary Scope of Work:
Other Scope of Work:
July, 2026 Page 3 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
What type of work does the firm self-perform? ______________________________________________
Provide a brief explanation (Note that the firm shall indicate the type(s) of work the firm's workforce and
equipment normally perform, licensure, and other pertinent information. Attach additional sheets as
needed.):
_____________________________________________________________________________________
Bonding:
1. e. (1) Attach letter, dated within the last 30 days, from your surety company, signed by their Attorney
in Fact, verifying their willingness to issue sufficient payment and performance bonds for this project, on
behalf of your firm and the dollar limits of that bond commitment, both single and aggregate. Surety
company bond rating shall be rated "A" or better under the A.M. Best Rating system or The Federal
Treasury List.
Have you attached a surety letter?
Yes No
1. e. (2) Have any Funds ever been expended by a Surety Company on your firm's behalf?
Yes No
If yes, please explain:
Insurance:
1. f. The minimum requirements of coverage are included in Appendix A (City of Raleigh Insurance
Requirements for a CONTRACT FOR CONSTRUCTION/REPAIR) located on pages 18 and 19 of this form. Firms
must indicate that they can provide evidence of insurance coverage should they be the successful bidder
by attaching a copy of their insurance certificate.
Have you attached a copy of your insurance certificate?
Yes No
Financials:
1. g. Attach a minimum of one year of complete audited financial statements from the past two years. If
financial statements have NOT been audited in the last two years, please provide the most recent
unaudited financial statements. Have you attached financial statement(s)?
July, 2026 Page 4 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
Yes No
SECTION 2. GENERAL REQUIREMENTS
Experience - Size/Capacity/Workload:
2. a. (1) List the annual dollar value of construction work the company has performed for each year over
the last (3) three calendar years as listed (if applicable).
2026
2025
2024
2. a. (2) How many projects do you currently have under contract or in progress and what is their total
dollar value?
* (# of projects);
* $ (Current projects contract amount);
* $ (Projects current amount remaining to bill)
2. a. (3) What was your largest job completed?
Sq. Ft.
$ Dollar Amount
Name of Project and Location
(City/State)
_____________________________________________________ Name of Owner, Designer, and General
Contractor
Year Completed
2. a. (4) Current Backlog:
$ ________ Dollar Amount
July, 2026 Page 5 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
2. a. (5) List the three largest contracts currently under contract or in progress, including for each, the
name of the project, owner, architect and/or GC/CMAR and contact information below.
1 -Project Name
Description of Work Performed
Contract Delivery Method (CMAR/GC)?
Owner Name/Representative
Owner Address/Phone #/Email
Architect Name/Representative
Architect Address/Phone #/Email
GC or CM Name/Representative
GC or CM Address/Phone #/Email
Contract Dollar Value
Percentage Complete
Current Anticipated Completion Date
#2 -Project Name
Description of Work Performed
Contract Delivery Method (CMAR/GC)?
Owner Name/ Representative
Owner Address/Phone #/Email
Architect Name/Representative
Architect Address/Phone #/Email
GC or CMAR Name/Representative
GC or CMAR Address/Phone #/Email
July, 2026 Page 6 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
Contract Dollar Value
Percentage Complete
Current Anticipated Completion Date
#3 -Project Name
Description of Work Performed
Contract Delivery Method (CMAR/GC)?
Owner Name/Representative
Owner Address/Phone #/Email
Architect Name/Representative
Architect Address/Phone #/Email
GC or CMAR Name/Representative
GC or CMAR Address/Phone #/Email
Contract Dollar Value
Percentage Complete
Current Anticipated Completion Date
Office Locations:
2. b. Will this project be managed and directed from an office in NC? An office in NC is defined as "The
principal place from which the trade or business of the bidder is directed or managed," per GS 143-59c).
Yes No
Location of Office Primarily Responsible for Work ____________________________________
July, 2026 Page 7 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
Litigation/Claims:
The firm will be required to submit information regarding its litigation history, including litigation with
owners and subcontractors.
2. c. (1) has your company been involved in any judgments, claims, arbitration or mediation proceedings,
or suits within the last five years, whether resolved or still pending resolution?
Yes No
If yes, state the project name(s), year(s), case number, and case disposition:
2. c. (2) Are there currently any judgments, claims, arbitration or mediation proceedings or suits pending
or outstanding against your company, its officers, owners, or agents?
Yes No
If yes, state the project name(s), year(s), case number, and case disposition (Provide additional sheets as
needed):
2. c. (3) Has your company ever failed to complete work awarded to it?
Yes No
If yes, state the project name(s), year(s) and reason why. (Provide additional sheets as needed):
2. c. (4) Have you ever paid liquidated damages on any project?
Yes No
If yes, state the project name(s), ), year(s) and reason why. (Provide additional sheets as needed):
2. c. (5) Has your present company, its officers, owners, or agents ever been convicted of charges relating
to conflicts of interest, bribery, or bid rigging?
Yes No
If yes, state the project name(s), year(s) and reason why. (Provide additional sheets as needed):
July, 2026 Page 8 of 14

Raleigh Police Department Evidence Facility project
Prequalification Form for Subcontractors
2. c. (6) Has your present company, its officers, owners, or agents ever been barred from bidding public
work?
Yes No
If yes, state the project name(s) and location(s), year(s), case number, and reason(s) why (Provide
additional sheets as needed):
Safety Record:
2. d. List your company's Experience Modification Rate (EMR) for past three years. (Attach OSHA 300 Log
for the last 3 years.). Firms must provide copies of any complaints, safety violations or reports from the
North Carolina Qualifications Board, OSHA, or any other regulating agency associated with any
construction project (i.e., OSHA 300 log). Have these documents been attached?
Yes No
Current rate:
2026 rate:
2025 rate:
2024 rate:
If these rates reflect corporate performance over a number of locations, please explain, to the extent
possible, the performance experience of the location serving this project:
List any OSHA fines and Jobsite fatalities in the past 3 years with an explanation:
2. e (1). Reserved
2. e (2). Reserved
July, 2026 Page 9 of 14