1412129846 (RFP) Dinsmore 26kV Metering Installation Addendum 1

Location:	Florida
Posted:	Mar 20, 2026
Due:	Mar 27, 2026
Agency:	JEA
Type of Government:	State & Local
Category:	Z - Maintenance, Repair or Alteration of Real Property
Solicitation No:	1412129846
Publication URL:	To access bid details, please log in.

1412129846 (RFP) Dinsmore 26kV Metering Installation

The scope of work includes furnishing all labor, supervision, equipment, and materials necessary to install structural steel supports, metering panels, junction boxes, metering combo units, and metering relay panels, along with associated grounding, conduit systems, and AC/DC control cabling. The work generally consists of mobilization, installation of foundations and grounding systems, placement of conduits and structures, installation of 26 kV equipment and associated components, pulling and terminating cables between yard equipment and control house panels, coordination with Owner personnel for wiring, testing, and commissioning, and completion of site cleanup, inspections, and punch list items prior to demobilization.

USE THIS LINK TO ACCESS THE SOLICITATION VIA ZYCUS

https://zsn.zycus.com/guest/genericRegister/JEA074/iSource/1032410/

Mandatory Pre-Bid Meeting: March 17, 2026

Optional Site Visit: March 18, 2026

Solicitation Due Date: March 27, 2026

1412129846 Solicitation

1412129846 - Appendix A - Technical Specifications

1412129846 Appendix B - Bid Forms

1412129846 Appendix B- Subcontractor Form

1412129846 Appendix C - Evaluation Matrix

1412129846 Addendum 1

1412129846 Addendum 1 - DN2018-CableSch_Rev6_REDUCED

DN26 - Sample Schedule of Values

1412129846 Mandatory Pre-Bid Attendees

Attachment Preview

1.1) Cover Page

Solicitation

For Participation in

Dinsmore 26kV Metering Installation

for

JEA

Jacksonville, FL

Solicitation Number 1412129846

Mandatory Pre-Response Meeting via Microsoft Teams on March 17, 2026 at 10:00AM EST

Microsoft Teams meeting

Join: https://teams.microsoft.com/meet/22265591479006?p=PvMm5Eg29eMSWtQQuw

Meeting ID: 222 655 914 790 06

Passcode: pP7hi7p9

Need help? | System reference

Dial in by phone

+1 469-208-1810,,576796503# United States, Carrollton

Find a local number

Phone conference ID: 576 796 503#

Join on a video conferencing device

Tenant key: jea@m.webex.com

Video ID: 113 974 125 5

More info

Optional Site Visit: March 18, 2026 at 09:30AM EST

Site Address: 12160 New Kings Road Jacksonville, Florida 32219

PPE Required (Steel Toe Boots, Safety Glasses, Hard Hat, etc)

Those planning to attend via Microsoft Teams should send contact information to: Jason Behr, behrjv@jea.com 48

hours prior to the Pre-Response Meeting to have contact information documented.

Responses are due on March 27, 2026 by 12:00 PM EST

All Responses shall be submitted through JEA’s E-Procurement and Contract Management Portal which is provided

by Zycus Supplier Network which can be accessed at https://zsn.zycus.com/guest. Instructions on how to login to

Zycus is provided below in this Solicitation. LATE RESPONSES MAY BE REJECTED.

JEA will publicly open all Responses received from qualified Respondents on the Due Date, via Microsoft Teams.

For more information please contact the JEA Buyer at:

Jason Behr, behrjv@jea.com

1.2) Scope of Work

The scope of work includes furnishing all labor, supervision, equipment, and materials necessary to install structural

steel supports, metering panels, junction boxes, metering combo units, and metering relay panels, along with

associated grounding, conduit systems, and AC/DC control cabling. The work generally consists of mobilization,

installation of foundations and grounding systems, placement of conduits and structures, installation of 26 kV

equipment and associated components, pulling and terminating cables between yard equipment and control house

panels, coordination with Owner personnel for wiring, testing, and commissioning, and completion of site cleanup,

inspections, and punch list items prior to demobilization.

1.3) Background

JEA owns, operates and manages the electric system established by the City of Jacksonville, Florida since 1895. In June

1997, JEA also assumed operation of the water and sewer system previously managed by the City. JEA is located in

Jacksonville, Florida, where we proudly serve an estimated 522,469 electric, 396,566 water and 316,441 sewer and

26,902 reuse water customers. JEA is Florida's largest community owned utility and the eighth largest municipal in the

United States.

1.4) Invitation - Submitting a Response

Respondents that meet the Minimum Qualification stated herein are invited to submit a Response to this Solicitation to

perform the Work. A complete copy of this Solicitation, the Technical Specifications, forms and all other documents

referenced in this Solicitation are on JEA’s E-Procurement and Contract Management Portal which is provided by

Zycus Supplier Network which can be accessed at https://zsn.zycus.com/guest/genericRegister/JEA074. Instructions

on how to login to Zycus is provided below in this Solicitation.

All Responses are due at the time indicated on the title page of this Solicitation. Section 1 of this Solicitation are the

instructions for submitting a Response for this Solicitation. Section 2 of this Solicitation contain the definitions and

commercial contract terms associated with this procurement.

A Contract will be presented to the Respondent awarded this Work and the Contract will incorporate by reference this

entire Solicitation and all associated Addenda. A sample of the JEA Contract can be found on jea.com.

All documentation submitted with a Response must reference the Solicitation Title and Number stated herein. All

Responses must be made on the appropriate forms and formats as specified by this Solicitation and uploaded to JEA’s

procurement platform.

All Responses should be delivered electronically to JEA via the Zycus platform. An automated, detailed auditing

system provides sealed Response integrity. Responses remain sealed on the platform until the Close Date & Time

(Due Date & Time).

A Respondent shall be solely responsible for timely delivery of its Response to the Zycus Supplier

Network. Respondents are strongly encouraged to acquire log in credentials early as possible. Additionally

Respondents are encouraged to submit Responses early to ensure uploading process goes smoothly. If Respondent is

not able to submit its Response via Zycus, then please email the Response to the JEA Buyer identified in the

Section below titled "Questions".

Responses are due by the time and on the date stated on the cover page of this Solicitation. LATE RESPONSES

MAY BE REJECTED.

1.5) Zycus Instructions

I. How to Log Into Zycus

A. New Users – Zycus

1. New Users will need to register to login. Registration will require Company name, address, phone, contact, title,

phone and email address. Also, it is recommended users use Google Chrome to access Zycus.

2. Note if the company is already doing business with JEA, you may find the company is already registered in Zycus.

To find out if you are registered, try entering your email address in the New User Registration screen. If you receive a

message stating “Email ID already registered”, log in as an Existing User Log-in”. If you don’t know your password,

enter your email address and click on “Forgot Password”.

B. Existing Users or New Users with Previously Registered Emails

1. Once the user has a login on the sourcing platform select “Existing User Log-in”, the user may navigate to the

solicitation by selecting the icon for the applicable solicitation.

II. How to Submit a Response Using Zycus

1. Once logged in, users will see all JEA Sourcing Events, then select the applicable event.

2. Once in the Sourcing Event. The Sourcing Event has prompts for actions required to respond to the solicitation.

3. For the user to proceed to submit a Response to JEA using Zycus, the user will be required to provide its acceptance

of the of the Zycus iSource Terms & Conditions associated with the work. Such Terms and Conditions may cover

non-disclosure, safety, cyber security, Invitation for Bid contract terms, etc.

4. Once all terms are accepted, additional Solicitation information will be available for viewing and submitting a

Response by selecting “Confirm Participation”. JEA will then have a record indicating the company intends to submit

a Response.

5. A user then can respond to each section of the Solicitation, once completed with each section, select “Save”. Note

each section has a red, yellow, green light code. Items will turn green once completed. Yellow and red lights mean

there is additional action required. Users may also note under each tab, there are multiple questions to respond to,

scroll down the list to ensure all questions are answered.

6. In most Solicitations, JEA will provide Technical Specifications, pricing tables in Excel which the user will need to

download. Additionally, Excel pricing tables may need to be uploaded once completed to as part of the Response.

Users can download the required attachments by selecting the “Buyers Attachments” icon.

7. Once the required forms are uploaded and saved, the section light will turn green. Once all sections are completed

and green lighted, the User may select “Submit Response”.

8. Once the user selects “Submit Response”, the user will receive a “Success” pop-up when submitted.

9. Once submitted users may recall and modify submitted documentation and submit information until the Response

Due Date and Time.

1.6) Questions

All Questions must be submitted in writing to the JEA Buyer listed herein at least five business days prior to the

opening date. Questions received within five business days prior to the opening date may not be answered.

1.7) Pre-Response Meeting

There may be a mandatory Pre-Response meeting associated with this Solicitation at the date and time listed on the

cover page of this Solicitation. All interested Respondents are invited to attend the Pre-Response meeting. Those

planning to attend the Microsoft Teams teleconference may email their name and contact information to the JEA

Buyer listed herein at least 48 hours prior to the Pre-Response meeting to facilitate roll call. A Respondent must only

1.8) Opening of Responses

All Responses received shall be publicly announced and recorded via Microsoft Teams at the date and time indicated

on the cover page of this Solicitation.

The details for the Microsoft Teams will be on jea.com at the following website: https://www.jea.com approximately

48 hours before the Response opening.

At the opening of Responses, a JEA representative will publicly open each Response that was received prior to the

Date and Time, except for those Responses that have been properly withdrawn. JEA has the right to waive

irregularities or informalities in the Responses to the extent allowable under applicable laws.

1.9) Alternate Provisions and Conditions (RFP&ITN)

Terms and conditions found in Responses that are contrary to requirements found in this Solicitation, including, but

not limited to, the Contract terms and conditions contained in Section 2 of this Solicitation and any requirements found

in the Technical Specifications attached as an exhibit or attachment to this Solicitation, will be rejected and are of no

force and effect. However, JEA reserves the right to negotiate different terms and conditions and requirements if JEA

determines that such terms and conditions and requirements are in the best interest of JEA.

1.10) Minimum Qualifications

Respondent must meet the following Minimum Qualifications to be considered eligible to have its Response evaluated

by JEA. Respondent must complete and submit the Minimum Qualification Form provided in this Solicitation.

Respondents that are working or have worked for JEA in the past 2 years involving similar work must submit JEA as a

reference. JEA reserves the right to ask for additional back up documentation or additional reference projects to

confirm the Respondent meets the requirements stated above.

JEA may reject Responses from Respondents not meeting all of the following Minimum Qualifications:

I. Respondent must not be on the State of Florida Convicted Vendor List, State of Florida’s Suspended Vendor List,

the City of Jacksonville’s Disqualified Vendor List, have their bidding privileges actively suspended by JEA,

been debarred by JEA, or have had a contract with JEA was terminated for default within the last two (2) years.

II. Respondent must be approved for RBL Category SB2 Substation Construction up to 500kV by the bid due date.

III. Respondents must clearly demonstrate in their proposal their ability to meet the schedule outlined in Appendix A

– Technical Specifications. Proposals that fail to show the respondent’s capability to meet the required schedule

may be deemed non-responsive and subject to rejection.

IV. The Respondent shall comply with the technical and commercial specifications for this solicitation.

1.11) Number of Contracts to be Awarded

JEA intends to Award one (1) Contract for the Work. JEA reserves the right to Award more than one Contract based

on certain groupings of the Work items, or JEA may exclude certain Work items, if JEA determines that it is in its best

interest.

1.12) Insurance Requirements

Prior to JEA issuing a Purchase Order to the Company to begin the Work, the Company shall submit a certificate of

insurance (COI) that is in compliance with amounts and requirements as indicated in this Solicitation. Note that the

COI shall specifically indicate JEA as additional insured on all required insurance except Worker's Compensation and

Professional Liability (if applicable). Furthermore, waiver of subrogation must be provided for all required insurance

in favor of JEA, including its board members, officers, employees, agents, successors, and assigns.

1.13) Jacksonville Small and Emerging Business (JSEB) Participation Goal - Optional

All questions and correspondence concerning the JSEB program should be addressed to the following contact:

Bill Hickey

Manager, Supplier Diversity Programs and Procurement Services

JEA

hickwj@jea.com or jsebprogram@jea.com

1.14) Basis of Award - Highest Evaluated

JEA will use the Selection Criteria listed below to evaluate the Responses. JEA may make its Award decision based

solely upon the information submitted in the Responses. JEA may also choose to have one or more Respondent make

presentations to representatives of JEA. It is always in the best interest of the Respondent to provide informative,

concise, well-organized technical and business information relative to the Work, in both the initial submittal of its

Response and in any subsequent submittals.

Please note, JEA may reject Responses that request material changes or take exceptions to JEA commercial terms and

conditions.

Responses will be scored and ranked by a committee of evaluators. Each evaluator will individually score the

Responses using the evaluation matrix attached to this Solicitation. Using these scores, each evaluator will rank the

Responses using "1" for the Response receiving the highest number of points from the matrix. Responses with an

equal number of points will receive the same numerical ranking. JEA will total the numerical rankings for each

Response and consider the Response with the lowest total to be the most highly qualified Response. Any tie will be

broken using the total of the matrix scores of all evaluators. If a tie persists, the tie will be broken in accordance with

the JEA Procurement Operational Procedures.

1.15) Selection Criteria

The following criteria will be used by JEA to evaluate and rank Responses from Respondents who meet the Minimum

Qualifications specified in this Solicitation.

1.16) Quotation of Rates (RFP) (50 Points)

Respondent shall provide a completed Response form for scope of services in this solicitation. Additionally, if

requested, the provider shall provide a completed the Response Workbook in Appendix B. The total Response price

should be entered on the Proposal Form. The total Response price shall firm fixed prices, not estimates, and include all

profit, taxes, benefits, and all other items. ANY MODIFICATIONS, EXCEPTION, OR OBJECTIONS CONTAINED

WITHIN THE RESPONSE FORM MAY SUBJECT THE RESPONSE TO DISQUALIFICATION.

1.17) Similar Experience (RFP) (10 Points)

The Respondent shall provide two references from previously completed projects that closely align with the scope,

complexity, and technical expertise needed for this project.

Includes:

1. Reference Project Name

2. Reference Company Name

3. Reference Email Address & Name

4. Year work completed

5. Contract Value $

6. Description of work and similar experiences to this project.

Similar experience includes:

1. Brownfield substation project which include modifications or additions to existing substation.

1.18) Schedule Submittal (RFP) (20 Points)

The Respondent shall provide a detailed project schedule that includes a comprehensive and realistic task breakdown,

including clear durations, dependencies, and resource allocation. Clearly identifies key project milestones, aligns with

critical path, and ensures adherence to JEA milestone and outage dates. See JEA Technical Specifications - Specific

Instructions for JEA Milestones.

1.19) Plan (RFP) (15 Points)

This is the opportunity summary page. It provides an overview of this opportunity and a preview of the attached documentation.

Daily notification on new contract opportunities

With GovernmentContracts, you can:

Find more opportunities and win more business
Receive daily alerts for all new bid opportunities
Get contract opportunities matched to your business

ONE WEEK FREE TRIAL

1412129846 (RFP) Dinsmore 26kV Metering Installation Addendum 1

Attachment Preview

See also