Crystal Lake Improvement

NOTICE TO RECEIVE SEALED BIDS
Washington County shall receive sealed bids from any qualified person, company or corporation
interested in constructing the:
CRYSTAL LAKE
This project will include the paving of Crystal Lake Road from the intersection of Tricia Trail to
Amethyst Lane for a total length of 4000 LF. The project will include drainage improvements using
a combination of swales with ditch blocks. Signage and pavement marking are also included during
construction.
Bid documents can be obtained at Dewberry, 20684 Central Avenue East, Blountstown, Florida
32424. For questions, please contact Jonathan Sims at (850) 354-5188 or jsims@dewberry.com.
The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.
Completion date for this project will be 150 days from the date of the Notice to Proceed presented
to the successful bidder.
Liquidated damages for failure to complete the project on the specified date will be set at $1,000.00
per day.
Please indicate on the envelope that this is a sealed bid for the "CRYSTAL LAKE
IMPROVEMENTS".
Bids will be received until 3:00 PM (CST) on May 18th, 2026, at the Washington County
Administrative Office, 1331 South Blvd., Chipley, FL 32428, and will be opened and read aloud on
May 18th , 2026, at 3:05 PM (CST). No proposal will be accepted after the established deadline.
The County will not be responsible for any delays related to the electronic submission of proposals.
Plans and Specifications will be available from Dewberry. Digital copies will be available free of
charge.
The Washington County Board of County Commissioners reserves the right to waive informalities in
any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in
the best interest of Washington County.
RESPONSIBLE VENDOR DETERMINATION
Respondent is hereby notified that Section 287.05701, Florida Statutes, requires that the County
may not request documentation of or consider a vendor's social, political, or ideological interests
when determining if the vendor is a responsible vendor.
ADVERTISEMENT FOR BIDS-00010