WSU Project Numbers

Location:	Michigan
Posted:	Oct 2, 2026
Due:	Oct 7, 2026
Agency:	Wayne State University
Type of Government:	State & Local
Category:	Y - Construction of Structures and Facilities
Publication URL:	To access bid details, please log in.

Release Date	Title	Mandatory Pre-Bid?	Pre-Bid Date	Contact	Due Date
09-17-2026	WSU Project Numbers - 023-428338 RFP - University Auditorium Lobby Renovation - 2026 Complete RFP Information Detailed Drawings & Specifications Appendix A - Prevailing wage Rates WHD 9917 General Information Regarding Fringe Benefits 2-2024 WHD 9918 Prevailing Wages Requirements on State Projects 2-2024 Official Rate Schedule Issued 11-01-2025 (with 4-2026 updates) Power Point Presentation Prebid Attendance Confirmation (will open during prebid meeting) Addendum #1 - Minutes of the Pre-Bid Meeting held 09-23-2026 Addendum #2 - posted 10-01-2026 Addendum #3 - posted 10-02-2026 Auditorium Lobby Renovation - Link to Submit Bids	Optional	09-23-2026 10:00 am	Brandy Gaines (313) 577-3712 BrandyG@wayne.edu	10-07-2026

Attachment Preview


5203 CASS AVE., DETROIT, MI 48202

ALTERNATES
1. ALTERNATE #1: MEN'S BATHROOM #108; EXISTING LIGHT FIXTURES TO BE REMOVED. REPLACE EXISTING LIGHTING WITH NEW RECESSED LED FIXTURES (SIZES AND LOCATIONS PER PLANS). REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION. 2. ALTERNATE #2: WOMEN'S BATHROOM #107; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH AND REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION. 3. ALTERNATE #3: EAST LOBBY #101; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH AND REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION. 4. ALTERNATE #4: WEST LOBBY #104; EXISTING EXTERIOR DOORS AND FRAMES TO BE REMOVED. PROVIDE NEW DOORS AND FRAMES TO MATCH EXISTING STYLE AND FINISH WITHIN EXISTING OPENINGS. NEW HARDWARE TO BE PROVIDED TO MATCH NEW DOOR FINISH; PANIC BARS, CONTINUOUS HINGES, AND CLOSER'S. 5. ALTERNATE #5: MEN'S BATHROOM #108; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING GROUT AND PROVIDE NEW GROUT, GRO-1. 6. ALTERNATE #6: WOMEN'S BATHROOM #107; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING GROUT AND PROVIDE NEW GROUT, GRO-1.

ALTERNATES

1. ALTERNATE #1: MEN'S BATHROOM #108; EXISTING LIGHT FIXTURES TO BE REMOVED. REPLACE EXISTING LIGHTING WITH NEW RECESSED LED FIXTURES (SIZES AND LOCATIONS PER PLANS). REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION. 2. ALTERNATE #2: WOMEN'S BATHROOM #107; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH AND REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION. 3. ALTERNATE #3: EAST LOBBY #101; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH AND REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION. 4. ALTERNATE #4: WEST LOBBY #104; EXISTING EXTERIOR DOORS AND FRAMES TO BE REMOVED. PROVIDE NEW DOORS AND FRAMES TO MATCH EXISTING STYLE AND FINISH WITHIN EXISTING OPENINGS. NEW HARDWARE TO BE PROVIDED TO MATCH NEW DOOR FINISH; PANIC BARS, CONTINUOUS HINGES, AND CLOSER'S. 5. ALTERNATE #5: MEN'S BATHROOM #108; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING GROUT AND PROVIDE NEW GROUT, GRO-1. 6. ALTERNATE #6: WOMEN'S BATHROOM #107; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING GROUT AND PROVIDE NEW GROUT, GRO-1.

1.	ALTERNATE #1:	MEN'S BATHROOM #108; EXISTING LIGHT FIXTURES TO BE REMOVED. REPLACE
	EXISTING LIGHTING WITH NEW RECESSED LED FIXTURES (SIZES AND LOCATIONS PER PLANS).
	REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION.
2.	ALTERNATE #2:	WOMEN'S BATHROOM #107; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH
	AND REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED
	RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR
	ADDITIONAL INFORMATION.
3.	ALTERNATE #3:	EAST LOBBY #101; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH AND
	REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED
	RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR
	ADDITIONAL INFORMATION.
4.	ALTERNATE #4:	WEST LOBBY #104; EXISTING EXTERIOR DOORS AND FRAMES TO BE REMOVED.
	OPENINGS. NEW HARDWARE TO BE PROVIDED TO MATCH NEW DOOR FINISH; PANIC BARS,
	CONTINUOUS HINGES, AND CLOSER'S.
5.	ALTERNATE #5:	MEN'S BATHROOM #108; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING
	GROUT AND PROVIDE NEW GROUT, GRO-1.
6.	ALTERNATE #6:	WOMEN'S BATHROOM #107; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING
	GROUT AND PROVIDE NEW GROUT, GRO-1.

DRAWING LIST - MECHANICAL
SHEET NUMBER		SHEET NAME
M01-01		DRAWING LIST & LEGENDS
MMD50-1-B01-01		LLEEVVEELL BB11 O HVVEARCA LDLE HMVOALCIT PIOLANN PLAN
MM5850--B011-01		LLEEVVEELL BB11 H OVVAECR DAELML OHLVITAICO NP LPALNAN

THE RENOVATION OF THE UNIVERSITY AUDITORIUM'S COMMON SPACES WILL INCLUDE REPAIRING
THE EXTERIOR DOORS, STAIR RAILINGS, AND GUARDRAILS, AS WELL AS UPDATING THE

BE REPLACED, THE TRAVERTINE FLOORING AND BASE WILL BE SELECTIVELY REPAIRED, AND
BOTH THE RESTROOM LAYOUTS ARE TO BE REWORKED TO BE BROUGHT UP TO CURRENT CODE
WITH UPDATED FINISHES.

DRAWING LIST - PLUMBING
SHEET NUMBER		SHEET NAME
PPD20-1-B01-01		LLEEVVEELL BB11 P DLRUAMIBNIANGGE P &LA WNASTER DEMOLITION PLAN
PP2820--B011-01		LLEEVVEELL BB11 D PRLAUIMNABGINEG & P WLAATNESR DEMOLITION PLAN

DRAWING LIST - ELECTRICAL
SHEET NUMBER		SHEET NAME
E01-01		ELECTRICAL GENERAL SHEET
E01-02		ELECTRICAL SPECIFICATIONS
EE1D01-00-101		PPOOWWEERR PALNADN LIGHTING DEMOLITION PLANS
EE1200--0011		PLIOGWHTEIRNG P LPALANNS
EE2D01-00-101		LPIOGWHETRIN AGN PDL LAINGSHTING DEMOLITION PLANS

ALTERNATES
1. ALTERNATE #1: MEN'S BATHROOM #108; EXISTING LIGHT FIXTURES TO BE REMOVED. REPLACE
EXISTING LIGHTING WITH NEW RECESSED LED FIXTURES (SIZES AND LOCATIONS PER PLANS).
REFER TO ELECTRICAL DRAWINGS FOR ADDITIONAL INFORMATION.
2. ALTERNATE #2: WOMEN'S BATHROOM #107; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH
AND REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED
RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR
ADDITIONAL INFORMATION.
3. ALTERNATE #3: EAST LOBBY #101; EXISTING LIGHT FIXTURES TO BE REMOVED. PATCH AND
REPAIR PLASTER CEILING AS REQUIRED TO ACCOMMODATE NEW FIXTURES. NEW LED
RECESSED CAN FIXTURES TO BE PROVIDED. REFER TO ELECTRICAL DRAWINGS FOR
ADDITIONAL INFORMATION.
4. ALTERNATE #4: WEST LOBBY #104; EXISTING EXTERIOR DOORS AND FRAMES TO BE REMOVED.
PROVIDE NEW DOORS AND FRAMES TO MATCH EXISTING STYLE AND FINISH WITHIN EXISTING
OPENINGS. NEW HARDWARE TO BE PROVIDED TO MATCH NEW DOOR FINISH; PANIC BARS,
CONTINUOUS HINGES, AND CLOSER'S.
5. ALTERNATE #5: MEN'S BATHROOM #108; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING
GROUT AND PROVIDE NEW GROUT, GRO-1.
6. ALTERNATE #6: WOMEN'S BATHROOM #107; EXISTING WALL TILE TO REMAIN. REMOVE EXISTING
GROUT AND PROVIDE NEW GROUT, GRO-1.
PHOTOGRAPH CREDIT BLAKE MCDONALD FOR HISTORIC DETROIT
150 W. Jefferson
Avenue., Suite 1300
Detroit, MI, US 48226
norr.com
NNOOIITTCCUURRTTSSNNOOCC
RROOFF
TTOONN
--
YYRRAANNIIMMIILLEERRPP
CLIENT SHEET INDEX ALTERNATES:
PROJECT DESCRIPTION:
PROJECT LOCATION
PROJECT LOCATION MAP
ARCH E - Cover Title Block - V2023 - Rev (July/23) - Copyright (C) 2023
MP
40:52:1
6202/9/7
tvr.52R_oneR_muirotiduA-inU_USW_HCRA_3310-6202DE_RRON/noitavoneR
muirotiduA
ytisrevinU
-
USW//:scoD
ksedotuA
WSU UNIVERSITY AUDITORIUM RENOVATION
5203 CASS AVE., DETROIT, MI 48202
NORR PROJECT NUMBER: ED2026-0133
BID SET - 07-09-2026
DRAWING LIST - ARCHITECTURAL
SHEET
NUMBER SHEET NAME
A00-00 COVER SHEET
A01-01 GENERAL NOTES, ABBREVIATIONS, & SYMBOL LEGEND
A03-01 ACCESSIBLE CLEARANCES & MOUNTING HEIGHTS
A10-01 OVERALL DEMOLITION FLOOR PLAN - UPPER BASEMENT LEVEL
A10-02 OVERALL DEMOLITION FLOOR PLAN - LEVEL 1
A11-01 OVERALL DEMOLITION REFLECTED CEILING PLAN - UPPER BASEMENT LEVEL
A11-02 OVERALL DEMOLITION REFLECTED CEILING PLAN - LEVEL 1
A20-01 OVERALL NEW WORK FLOOR PLAN - UPPER BASEMENT LEVEL
A20-02 OVERALL NEW WORK FLOOR PLAN - LEVEL 1
A22-01 OVERALL FLOOR FINISH PLAN - UPPER BASEMENT LEVEL
A22-02 OVERALL FLOOR FINISH PLAN - LEVEL 1
A30-01 OVERALL NEW WORK REFLECTED CEILING PLAN - UPPER BASEMENT LEVEL
A30-02 OVERALL NEW WORK REFLECTED CEILING PLAN - LEVEL 1
A60-01 ENLARGED NEW WORK UPPER BASEMENT LEVEL PLAN AND ELEVATIONS
DRAWING LIST - MECHANICAL THE RENOVATION OF THE UNIVERSITY AUDITORIUM'S COMMON SPACES WILL INCLUDE REPAIRING
THE EXTERIOR DOORS, STAIR RAILINGS, AND GUARDRAILS, AS WELL AS UPDATING THE
SHEET ENTRANCE LOBBY LIGHTING. ADDITIONALLY, THE EXISTING VCT FLOORING AND VINYL BASE WILL
BE REPLACED, THE TRAVERTINE FLOORING AND BASE WILL BE SELECTIVELY REPAIRED, AND
NUMBER SHEET NAME
BOTH THE RESTROOM LAYOUTS ARE TO BE REWORKED TO BE BROUGHT UP TO CURRENT CODE
M01-01 DRAWING LIST & LEGENDS WITH UPDATED FINISHES.
MMD50-1-B01-01 LLEEVVEELL BB11 O HVVEARCA LDLE HMVOALCIT PIOLANN PLAN
MM5850--B011-01 LLEEVVEELL BB11 H OVVAECR DAELML OHLVITAICO NP LPALNAN
DRAWING LIST - PLUMBING
SHEET
NUMBER SHEET NAME
PPD20-1-B01-01 LLEEVVEELL BB11 P DLRUAMIBNIANGGE P &LA WNASTER DEMOLITION PLAN
PP2820--B011-01 LLEEVVEELL BB11 D PRLAUIMNABGINEG & P WLAATNESR DEMOLITION PLAN
DRAWING LIST - ELECTRICAL
SHEET
NUMBER SHEET NAME
E01-01 ELECTRICAL GENERAL SHEET
E01-02 ELECTRICAL SPECIFICATIONS
EE1D01-00-101 PPOOWWEERR PALNADN LIGHTING DEMOLITION PLANS
EE1200--0011 PLIOGWHTEIRNG P LPALANNS
EE2D01-00-101 LPIOGWHETRIN AGN PDL LAINGSHTING DEMOLITION PLANS

DATE	ISSUED FOR	REV
05-15-2026	50% CONSTRUCTION DOCUMENTS
07-09-2026	BID SET
NNOOIITTCCUU
RR This drawing has been prepared solely for the use of WAYNE STATE UNIVERSITY and there are no representations of any kind made by NORR to any party with whom NORR has not entered into a contract.
TT This drawing shall not be used for construction purposes until the seal appearing hereon is signed and dated by the Architect or Engineer

INSTRUCTIONS FOR PRICING
DEFINITIONS: "OWNER" OR "LANDLORD" REFERS TO THE ENTITY NOTED ON THE DRAWING COVER SHEET AS "CLIENT" "ARCHITECT" REFERS TO NORR DESIGN, INC. "BIDDER" REFERS TO PERSON OR ENTITY WHO SUBMITS A BID AS A GENERAL CONTRACTOR. 1. BIDDER SHALL CAREFULLY STUDY AND COMPARE BIDDING DOCUMENTS WITH EACH SUBCONTRACTOR, AND WITH OTHER WORK BEING BID CONCURRENTLY TO EXTENT THAT IT RELATES TO WORK FOR WHICH BID IS SUBMITTED, SHALL EXAMINE SITE AND LOCAL CONDITIONS, AND SHALL AT ONCE REPORT ANY ERRORS, INCONSISTENCIES OR AMBIGUITIES DISCOVERED, IN WRITING, TO THE ARCHITECT. 2. IN CASE OF AN INCONSISTENCY BETWEEN DRAWINGS AND SPECIFICATIONS OR WITHIN EITHER DOCUMENT NOT CLARIFIED, MORE SPECIFIC PROVISION WILL TAKE PRECEDENCE OVER LESS SPECIFIC; MORE STRINGENT WILL TAKE PRECEDENCE OVER LESS STRINGENT; MORE EXPENSIVE ITEM WILL TAKE PRECEDENCE OVER LESS EXPENSIVE. BETTER QUALITY OR GREATER QUANTITY OF WORK SHALL BE PROVIDED IN ACCORDANCE WITH ARCHITECT'S INTERPRETATION. ON DRAWINGS, FIGURES TAKE PRECEDENCE OVER SCALED DIMENSIONS. SCALING OF DIMENSIONS, IF DONE, IS DONE AT BIDDER'S OWN RISK. 3. MATERIALS, PRODUCTS, AND EQUIPMENT DESCRIBED IN CONTRACT DOCUMENTS ESTABLISH STANDARD OF REQUIRED FUNCTION, DIMENSION, APPEARANCE, AND QUALITY REQUIRED FOR THE PROJECT. 4. BIDDER REPRESENTS, BY SUBMISSION OF A BID, THAT BID IS BASED UPON PRODUCTS, EQUIPMENT AND EXECUTION OF WORK AS DESCRIBED IN CONTRACT DOCUMENTS. NO SUBSTITUTIONS SHALL BE ALLOWED DURING PRICING.

INSTRUCTIONS FOR PRICING

DEFINITIONS: "OWNER" OR "LANDLORD" REFERS TO THE ENTITY NOTED ON THE DRAWING COVER SHEET AS "CLIENT" "ARCHITECT" REFERS TO NORR DESIGN, INC. "BIDDER" REFERS TO PERSON OR ENTITY WHO SUBMITS A BID AS A GENERAL CONTRACTOR. 1. BIDDER SHALL CAREFULLY STUDY AND COMPARE BIDDING DOCUMENTS WITH EACH SUBCONTRACTOR, AND WITH OTHER WORK BEING BID CONCURRENTLY TO EXTENT THAT IT RELATES TO WORK FOR WHICH BID IS SUBMITTED, SHALL EXAMINE SITE AND LOCAL CONDITIONS, AND SHALL AT ONCE REPORT ANY ERRORS, INCONSISTENCIES OR AMBIGUITIES DISCOVERED, IN WRITING, TO THE ARCHITECT. 2. IN CASE OF AN INCONSISTENCY BETWEEN DRAWINGS AND SPECIFICATIONS OR WITHIN EITHER DOCUMENT NOT CLARIFIED, MORE SPECIFIC PROVISION WILL TAKE PRECEDENCE OVER LESS SPECIFIC; MORE STRINGENT WILL TAKE PRECEDENCE OVER LESS STRINGENT; MORE EXPENSIVE ITEM WILL TAKE PRECEDENCE OVER LESS EXPENSIVE. BETTER QUALITY OR GREATER QUANTITY OF WORK SHALL BE PROVIDED IN ACCORDANCE WITH ARCHITECT'S INTERPRETATION. ON DRAWINGS, FIGURES TAKE PRECEDENCE OVER SCALED DIMENSIONS. SCALING OF DIMENSIONS, IF DONE, IS DONE AT BIDDER'S OWN RISK. 3. MATERIALS, PRODUCTS, AND EQUIPMENT DESCRIBED IN CONTRACT DOCUMENTS ESTABLISH STANDARD OF REQUIRED FUNCTION, DIMENSION, APPEARANCE, AND QUALITY REQUIRED FOR THE PROJECT. 4. BIDDER REPRESENTS, BY SUBMISSION OF A BID, THAT BID IS BASED UPON PRODUCTS, EQUIPMENT AND EXECUTION OF WORK AS DESCRIBED IN CONTRACT DOCUMENTS. NO SUBSTITUTIONS SHALL BE ALLOWED DURING PRICING.

SUBMITTALS
1. THE CONTRACTOR IS TO SCHEDULE SUBMITTALS SO THAT ARCHITECT AND BUILDING OWNER MAY REVIEW THEM IN A SEQUENCE WHICH REFLECTS THE LOGICAL SEQUENCE OF THE WORK AND THE RELATIVE PRIORITY OF THE CONSTRUCTION COMPONENTS. WHEN APPROPRIATE, SCHEDULE AND COORDINATE SUBMITTALS FOR RELATED WORK SO THAT ITEMS WHICH MUST BE COORDINATED, SUCH AS COLORS OF FINISHES, MAY BE REVIEWED TOGETHER. 2. THE CONTRACTOR IS TO REVIEW EACH SUBMITTAL FROM SUBCONTRACTORS AND SUPPLIERS AND VERIFY ACCURACY OF CONTENTS. AT A MINIMUM, VERIFY: MATERIALS, FIELD DIMENSIONS, ADJACENT CONSTRUCTION, CONFORMANCE WITH SPECIFIED ENVIRONMENTAL AND JOB CONDITIONS, COORDINATION WITH OTHER WORK, AND CONFORMANCE WITH THE CONTRACT DOCUMENTS. 3. THE CONTRACTOR IS TO REVIEW, STAMP AND SIGN EACH SUBMITTAL TO ATTEST THAT IT HAS BEEN REVIEWED BY THE CONTRACTOR, AND TRANSMIT TO THE ARCHITECT AND OWNER. THE CONTRACTOR SHALL ELECTRONICALLY TRANSMIT A PDF WITH A LETTER OF TRANSMITTAL. TRANSMITTALS WILL NOT BE ACCEPTED VIA FACSIMILE MACHINE. PROVIDE CLEARLY READABLE COPIES. DO NOT SUBMIT COPIES WHICH ARE MULTIPLE-GENERATION PHOTOCOPIES OR FACSIMILE COPIES UNLESS TEXT AND DIAGRAMS ARE CLEAR AND PLAINLY READABLE. 4. THE CONTRACTOR IS TO SUBMIT SHOP DRAWINGS AS FOLLOWS: PREPARE SHOP DRAWINGS SPECIFIC TO THIS PROJECT TO DESCRIBE THE FABRICATION AND INSTALLATION OF PRODUCTS; MANUFACTURER'S PREPRINTED STANDARD DETAILS ARE NOT SHOP DRAWINGS. DRAW CLEARLY AND PRESENT COMPLETE INFORMATION. INCLUDE PLANS, ELEVATIONS AND LARGE SCALE DETAILS, AS APPROPRIATE TO THE WORK SHOWN. NOTE FIELD DIMENSIONS AND ADJACENT CONSTRUCTION. INCLUDE SCHEDULES, PATTERNS, CALCULATIONS AND INSTRUCTIONS REGARDING COORDINATION AND INSTALLATION AS REQUIRED. IDENTIFY DETAILS BY REFERENCE TO CONTRACT DRAWING SHEET AND DETAIL, SCHEDULE, ROOM NUMBER, DOOR NUMBER OR OTHER APPLICABLE IDENTIFICATION. 5. THE CONTRACTOR IS TO SUBMIT PRODUCT DATA AS FOLLOWS: SUBMIT MANUFACTURER'S PRE- PRINTED DATA. CLEARLY MARK EACH COPY TO IDENTIFY PERTINENT PRODUCTS OR MODELS; CROSS- OUT INFORMATION WHICH IS NOT APPLICABLE TO THE WORK AND SUPPLEMENT STANDARD INFORMATION TO PROVIDE INFORMATION WHICH IS SPECIFICALLY APPLICABLE TO THE WORK. SHOW PERFORMANCE CHARACTERISTICS AND CAPACITIES. SHOW DIMENSIONS AND CLEARANCES REQUIRED. SHOW WIRING OR PIPING DIAGRAMS AND CONTROLS. SHOW DIMENSIONS AND CLEARANCES REQUIRED FOR PROPER OPERATION AND MAINTENANCE. SHOP DRAWINGS AND ARCHITECT'S REVIEW WILL BE SENT BACK ELECTRONICALLY. CONTRACTOR TO PRINT AND DISTRIBUTE COPIES TO SUBCONTRACTORS. 6. THE CONTRACTOR IS TO SUBMIT SAMPLES AS FOLLOWS: PROVIDE SAMPLES OF ADEQUATE SIZE TO PERMIT PROPER EVALUATION OF MATERIAL. WHERE VARIATIONS IN COLOR OR IN OTHER CHARACTERISTICS ARE TO BE EXPECTED, SUBMIT SAMPLES SHOWING THE MAXIMUM RANGE OF VARIATION. SUBMIT ALL SAMPLES OF INTERIOR FINISHES SIMULTANEOUSLY TO PERMIT COORDINATED SELECTION OF COLORS AND FINISHES. TAG OR PERMANENTLY MARK EACH SAMPLE TO IDENTIFY THE ITEM; INDICATE APPLICABLE TRANSMITTAL NUMBER ON TAG. SUBMIT 2 OF EACH TYPE REQUIRED, UNLESS OTHERWISE SPECIFIED IN THE SECTION REQUIRING THE SAMPLES. 7. PROVIDE CERTIFICATIONS, QUALIFICATION STATEMENTS, TEST REPORTS AND SIMILAR SUBMITTALS WHERE SPECIFIED FOR SUBMITTALS, QUALITY ASSURANCE, OR QUALITY CONTROL. 8. THE ARCHITECT AND BUILDING OWNER WILL REVIEW SUBMITTALS AS FOLLOWS: THE ARCHITECT AND BUILDING OWNER WILL REVIEW ONLY THOSE SUBMITTALS EXPLICITLY REQUIRED BY THE CONTRACT DOCUMENTS OR REQUESTED BY THE ARCHITECT AS THE WORK PROCEEDS. THE ARCHITECT WILL STAMP EACH SUBMITTAL TO INDICATE THE ACTION TAKEN. FABRICATION OR INSTALLATION OF WORK FOR WHICH ARCHITECT'S REVIEW IS REQUIRED SHOULD NOT BEGIN UNTIL THE SUBMITTAL IS ACCEPTABLE TO THE ARCHITECT. FABRICATION OR INSTALLATION BEGUN WITHOUT ARCHITECT'S ACCEPTANCE IS UNDERTAKEN AT THE CONTRACTOR'S SOLE RISK. IF SUBMITTAL IS STAMPED "NO EXCEPTIONS TAKEN" OR "MAKE CORRECTIONS NOTED", THE SHOP DRAWINGS, PRODUCT DATA OR SAMPLES NEED NOT BE RESUBMITTED. MAKE CHANGES NOTED TO THE ACTUAL ITEM PRIOR TO FABRICATION AND INSTALLATION. 9. RESUBMISSION: IF SUBMITTAL IS STAMPED "REVISE AND RESUBMIT", MAKE CORRECTIONS OR CHANGES REQUIRED BY THE ARCHITECT IN THE SUBMITTALS AND RESUBMIT UNTIL ACCEPTED. IF SUBMITTAL IS STAMPED "REJECTED", RESUBMIT IN CONFORMANCE WITH THE CONTRACT DOCUMENTS. IN RESUBMITTING, COMPLY WITH REQUIREMENTS SPECIFIED FOR THE INITIAL SUBMITTAL. TRANSMIT EACH RESUBMITTAL WITH A NEW LETTER OF TRANSMITTAL AND NOTE THE TRANSMITTAL NUMBER OF THE FIRST SUBMISSION ON THE TRANSMITTAL FORM. 10.SHOP DRAWINGS ARE REQUIRED FOR ALL FABRICATED ITEMS, INCLUDING BUT NOT LIMITED TO: * MILLWORK * LIGHT FIXTURES * CEILING SYSTEMS

SUBMITTALS

1. THE CONTRACTOR IS TO SCHEDULE SUBMITTALS SO THAT ARCHITECT AND BUILDING OWNER MAY REVIEW THEM IN A SEQUENCE WHICH REFLECTS THE LOGICAL SEQUENCE OF THE WORK AND THE RELATIVE PRIORITY OF THE CONSTRUCTION COMPONENTS. WHEN APPROPRIATE, SCHEDULE AND COORDINATE SUBMITTALS FOR RELATED WORK SO THAT ITEMS WHICH MUST BE COORDINATED, SUCH AS COLORS OF FINISHES, MAY BE REVIEWED TOGETHER. 2. THE CONTRACTOR IS TO REVIEW EACH SUBMITTAL FROM SUBCONTRACTORS AND SUPPLIERS AND VERIFY ACCURACY OF CONTENTS. AT A MINIMUM, VERIFY: MATERIALS, FIELD DIMENSIONS, ADJACENT CONSTRUCTION, CONFORMANCE WITH SPECIFIED ENVIRONMENTAL AND JOB CONDITIONS, COORDINATION WITH OTHER WORK, AND CONFORMANCE WITH THE CONTRACT DOCUMENTS. 3. THE CONTRACTOR IS TO REVIEW, STAMP AND SIGN EACH SUBMITTAL TO ATTEST THAT IT HAS BEEN REVIEWED BY THE CONTRACTOR, AND TRANSMIT TO THE ARCHITECT AND OWNER. THE CONTRACTOR SHALL ELECTRONICALLY TRANSMIT A PDF WITH A LETTER OF TRANSMITTAL. TRANSMITTALS WILL NOT BE ACCEPTED VIA FACSIMILE MACHINE. PROVIDE CLEARLY READABLE COPIES. DO NOT SUBMIT COPIES WHICH ARE MULTIPLE-GENERATION PHOTOCOPIES OR FACSIMILE COPIES UNLESS TEXT AND DIAGRAMS ARE CLEAR AND PLAINLY READABLE. 4. THE CONTRACTOR IS TO SUBMIT SHOP DRAWINGS AS FOLLOWS: PREPARE SHOP DRAWINGS SPECIFIC TO THIS PROJECT TO DESCRIBE THE FABRICATION AND INSTALLATION OF PRODUCTS; MANUFACTURER'S PREPRINTED STANDARD DETAILS ARE NOT SHOP DRAWINGS. DRAW CLEARLY AND PRESENT COMPLETE INFORMATION. INCLUDE PLANS, ELEVATIONS AND LARGE SCALE DETAILS, AS APPROPRIATE TO THE WORK SHOWN. NOTE FIELD DIMENSIONS AND ADJACENT CONSTRUCTION. INCLUDE SCHEDULES, PATTERNS, CALCULATIONS AND INSTRUCTIONS REGARDING COORDINATION AND INSTALLATION AS REQUIRED. IDENTIFY DETAILS BY REFERENCE TO CONTRACT DRAWING SHEET AND DETAIL, SCHEDULE, ROOM NUMBER, DOOR NUMBER OR OTHER APPLICABLE IDENTIFICATION. 5. THE CONTRACTOR IS TO SUBMIT PRODUCT DATA AS FOLLOWS: SUBMIT MANUFACTURER'S PRE- PRINTED DATA. CLEARLY MARK EACH COPY TO IDENTIFY PERTINENT PRODUCTS OR MODELS; CROSS- OUT INFORMATION WHICH IS NOT APPLICABLE TO THE WORK AND SUPPLEMENT STANDARD INFORMATION TO PROVIDE INFORMATION WHICH IS SPECIFICALLY APPLICABLE TO THE WORK. SHOW PERFORMANCE CHARACTERISTICS AND CAPACITIES. SHOW DIMENSIONS AND CLEARANCES REQUIRED. SHOW WIRING OR PIPING DIAGRAMS AND CONTROLS. SHOW DIMENSIONS AND CLEARANCES REQUIRED FOR PROPER OPERATION AND MAINTENANCE. SHOP DRAWINGS AND ARCHITECT'S REVIEW WILL BE SENT BACK ELECTRONICALLY. CONTRACTOR TO PRINT AND DISTRIBUTE COPIES TO SUBCONTRACTORS. 6. THE CONTRACTOR IS TO SUBMIT SAMPLES AS FOLLOWS: PROVIDE SAMPLES OF ADEQUATE SIZE TO PERMIT PROPER EVALUATION OF MATERIAL. WHERE VARIATIONS IN COLOR OR IN OTHER CHARACTERISTICS ARE TO BE EXPECTED, SUBMIT SAMPLES SHOWING THE MAXIMUM RANGE OF VARIATION. SUBMIT ALL SAMPLES OF INTERIOR FINISHES SIMULTANEOUSLY TO PERMIT COORDINATED SELECTION OF COLORS AND FINISHES. TAG OR PERMANENTLY MARK EACH SAMPLE TO IDENTIFY THE ITEM; INDICATE APPLICABLE TRANSMITTAL NUMBER ON TAG. SUBMIT 2 OF EACH TYPE REQUIRED, UNLESS OTHERWISE SPECIFIED IN THE SECTION REQUIRING THE SAMPLES. 7. PROVIDE CERTIFICATIONS, QUALIFICATION STATEMENTS, TEST REPORTS AND SIMILAR SUBMITTALS WHERE SPECIFIED FOR SUBMITTALS, QUALITY ASSURANCE, OR QUALITY CONTROL. 8. THE ARCHITECT AND BUILDING OWNER WILL REVIEW SUBMITTALS AS FOLLOWS: THE ARCHITECT AND BUILDING OWNER WILL REVIEW ONLY THOSE SUBMITTALS EXPLICITLY REQUIRED BY THE CONTRACT DOCUMENTS OR REQUESTED BY THE ARCHITECT AS THE WORK PROCEEDS. THE ARCHITECT WILL STAMP EACH SUBMITTAL TO INDICATE THE ACTION TAKEN. FABRICATION OR INSTALLATION OF WORK FOR WHICH ARCHITECT'S REVIEW IS REQUIRED SHOULD NOT BEGIN UNTIL THE SUBMITTAL IS ACCEPTABLE TO THE ARCHITECT. FABRICATION OR INSTALLATION BEGUN WITHOUT ARCHITECT'S ACCEPTANCE IS UNDERTAKEN AT THE CONTRACTOR'S SOLE RISK. IF SUBMITTAL IS STAMPED "NO EXCEPTIONS TAKEN" OR "MAKE CORRECTIONS NOTED", THE SHOP DRAWINGS, PRODUCT DATA OR SAMPLES NEED NOT BE RESUBMITTED. MAKE CHANGES NOTED TO THE ACTUAL ITEM PRIOR TO FABRICATION AND INSTALLATION. 9. RESUBMISSION: IF SUBMITTAL IS STAMPED "REVISE AND RESUBMIT", MAKE CORRECTIONS OR CHANGES REQUIRED BY THE ARCHITECT IN THE SUBMITTALS AND RESUBMIT UNTIL ACCEPTED. IF SUBMITTAL IS STAMPED "REJECTED", RESUBMIT IN CONFORMANCE WITH THE CONTRACT DOCUMENTS. IN RESUBMITTING, COMPLY WITH REQUIREMENTS SPECIFIED FOR THE INITIAL SUBMITTAL. TRANSMIT EACH RESUBMITTAL WITH A NEW LETTER OF TRANSMITTAL AND NOTE THE TRANSMITTAL NUMBER OF THE FIRST SUBMISSION ON THE TRANSMITTAL FORM. 10.SHOP DRAWINGS ARE REQUIRED FOR ALL FABRICATED ITEMS, INCLUDING BUT NOT LIMITED TO: * MILLWORK * LIGHT FIXTURES * CEILING SYSTEMS

GENERAL NOTES
1. ALL WORK UNDER THIS CONTRACT SHALL BE GOVERNED BY AIA DOCUMENT A201, GENERAL CONDITIONS OF THE CONTRACT, LATEST EDITION. IF ANY CONFLICTS BETWEEN THESE DRAWINGS AND DOCUMENT A201 ARISE, THE MORE STRINGENT OF THE TWO REQUIREMENTS SHALL APPLY. 2. THE INTENT OF THE CONTRACT DOCUMENTS IS TO ALLOW FOR THE PERFORMANCE OF THE WORK. EVERY ITEM NECESSARILY REQUIRED MAY NOT BE SPECIFICALLY MENTIONED OR SHOWN. UNLESS OTHERWISE INDICATED IN THE CONSTRUCTION DOCUMENTS AS BEING NOT IN CONTRACT (N.I.C., NIC) OR EXISTING, ALL SYSTEMS AND EQUIPMENT SHALL BE COMPLETED AND APPROPRIATELY OPERABLE. FURNISH AND INSTALL ALL SPECIFIED AND APPROPRIATE ITEMS, AND ALL INCIDENTAL, ACCESSORY, AND OTHER ITEMS NOT SPECIFIED BUT REQUIRED FOR A COMPLETE AND FINISHED ASSEMBLY. 3. NO WORK DEFECTIVE IN WORKMANSHIP OR QUALITY OR DEFICIENT IN ANY REQUIREMENTS OF THE CONTRACT DOCUMENTS WILL BE ACCEPTABLE, WHETHER OR NOT THE ARCHITECT DISCOVERS OR POINTS OUT DEFECTS OR DEFICIENCIES DURING CONSTRUCTION. DEFECTIVE WORK REVEALED WITHIN THE TIME REQUIRED BY WARRANTEES SHALL BE REPLACED BY WORK CONFORMING WITH THE INTENT OF THE CONTRACT. NO PAYMENT, EITHER PARTIAL OR FINAL, SHALL BE CONSTRUED AS AN ACCEPTANCE OF DEFECTIVE WORK OR IMPROPER MATERIALS. 4. IT IS INTENDED THAT THE CONTRACTOR PROVIDE A COMPLETE JOB AND ANY OMISSIONS IN THESE NOTES OR IN THE OUTLINE OF WORK SHALL NOT BE CONSTRUED AS RELIEVING THE CONTRACTOR OF SUCH RESPONSIBILITIES IMPLIED BY THE SCOPE OF WORK, EXCEPT FOR ITEMS SPECIFICALLY NOTED. 5. SHOULD ANY PORTION OF THE CONTRACT DOCUMENTS PROVE TO BE UNENFORCEABLE FOR WHATEVER REASON, SUCH UNENFORCEABILITY SHALL NOT EXTEND TO THE REMAINDER OF THE CONTRACT NOR SHALL IT VOID ANY OTHER PROVISIONS OF THE CONTRACT. 6. THROUGHOUT THE DURATION OF THE PROJECT, THE CONTRACTOR SHALL REFRAIN FROM ACTIONS THAT COULD LEAD TO THE FILING OF CLAIMS OF LIEN BY SUBCONTRACTORS, SUPPLIERS OF MATERIALS, LABOR, SERVICE, EQUIPMENT OR ANY OTHER INDIVIDUAL OR COMPANY SO ENTITLED UNDER GOVERNING LAWS AND REGULATIONS UNLESS REASONABLE AND JUSTIFIABLE CAUSE CAN BE SHOWN. APPROVAL FOR PAYMENT SHALL BE CONTINGENT UPON THE CONTRACTOR'S OBTAINING AND FURNISHING TO THE OWNER SIGNED RELEASES FROM SUCH INDIVIDUALS OR COMPANIES. 7. THE CONTRACTOR IS RESPONSIBLE FOR CHECKING CONTRACT DOCUMENTS, FIELD CONDITIONS AND DIMENSIONS FOR ACCURACY AND CONFIRMING THAT WORK IS BUILDABLE AS SHOWN BEFORE PROCEEDING WITH CONSTRUCTION. IF THERE ARE ANY QUESTIONS REGARDING THESE OR OTHER COORDINATION ISSUES, THE CONTRACTOR SHALL SUBMIT THEM, IN WRITING, TO THE ARCHITECT AND IS RESPONSIBLE FOR OBTAINING A WRITTEN CLARIFICATION FROM THE ARCHITECT BEFORE PROCEEDING WITH WORK IN QUESTION, OR RELATED WORK. 8. IN THE EVENT OF DISCREPANCIES BETWEEN ANY DRAWINGS AND/OR SPECIFICATIONS, THE MORE COSTLY AND/OR MORE RESTRICTIVE CONDITION SHALL BE DEEMED THE CONTRACT REQUIREMENT, UNLESS OTHERWISE STATED IN WRITING FROM THE OWNER. 9. EXECUTE WORK IN ACCORDANCE WITH ANY AND ALL APPLICABLE LOCAL, STATE, AND FEDERAL CODES, MANUFACTURER'S RECOMMENDATIONS, TRADE AND REFERENCED STANDARDS INCLUDING BUT NOT LIMITED TO: NEC, NFPA, ASTM, ASHRAE, LATEST ADOPTED EDITIONS. THESE SHALL SUPERSEDE DRAWINGS, NOTES AND DIMENSIONS IN ALL CASES. THE ARCHITECT SHALL BE NOTIFIED OF SUCH CHANGES BEFORE WORK IS STARTED. OBTAIN PERMITS BEFORE STARTING WORK, AND OBTAIN APPROVALS OF ALL REGULATORY AGENCIES UPON COMPLETION, AND AS REQUIRED. 10.THE GENERAL CONTRACTOR IS RESPONSIBLE FOR PAYING FOR AND OBTAINING ALL PERMITS, INSPECTIONS, REQUIRED TESTS AND UTILITY CONNECTIONS UNLESS OTHERWISE NOTED. 11.DO NOT SCALE DRAWINGS; DIMENSIONS SHALL GOVERN. DETAILS SHALL GOVERN OVER PLANS AND ELEVATIONS. LARGE SCALE DETAILS SHALL GOVERN OVER SMALL SCALE DETAILS. WRITTEN SPECIFICATIONS SHALL GOVERN OVER ALL. 12.CLARIFY ALL DISCREPANCIES AND QUESTIONS RELATIVE TO CONSTRUCTION DOCUMENTS, SPECIFICATIONS, AND FIELD CONDITIONS PRIOR TO SUBMITTING BIDS OR COMMENCING WORK. BY SUBMITTING THEIR BID, THE CONTRACTOR ATTESTS THAT THEY HAVE NO OPEN QUESTIONS RELATED TO THE CONSTRUCTION DOCUMENTS AND IS THEREFORE NOT ENTITLED TO ADDITIONAL COMPENSATION RELATED TO ANY ITEMS THEY DEEM TO BE UNCLEAR. 13.THERE SHALL BE NO SUBSTITUTION OF MATERIAL WHERE A MANUFACTURER IS SPECIFIED. WHERE THE TERM "OR EQUAL" IS USED, THE ARCHITECT ALONE SHALL DETERMINE EQUALITY BASED UPON INFORMATION SUBMITTED BY THE CONTRACTOR. 14.THE CONTRACTOR SHALL BE RESPONSIBLE FOR THE DISTRIBUTION OF DRAWINGS TO ALL TRADES UNDER THEIR JURISDICTION OR AUTHORITY. 15.DO NOT PROCEED WITH ANY WORK REQUIRING ADDITIONAL COMPENSATION BEYOND THE CONTRACT AMOUNT WITHOUT WRITTEN AUTHORIZATION FROM THE OWNER. FAILURE TO OBTAIN AUTHORIZATION SHALL INVALIDATE ANY CLAIM FOR EXTRA COMPENSATION. 16.ALL INSTALLED PLUMBING, MECHANICAL, AND ELECTRICAL EQUIPMENT SHALL OPERATE QUIETLY AND FREE OF VIBRATION. 17.ALL MATERIALS SHALL BE NEW, UNUSED, AND OF THE HIGHEST QUALITY IN EVERY RESPECT UNLESS OTHERWISE NOTED. MANUFACTURED MATERIALS AND EQUIPMENT SHALL BE INSTALLED AS PER MANUFACTURER'S RECOMMENDATIONS AND INSTRUCTIONS, U.O.N. 18.THE CONTRACTOR AND SUBCONTRACTORS SHALL PURCHASE AND MAINTAIN CERTIFICATIONS OF INSURANCE WITH RESPECT TO WORKERS COMPENSATION, PUBLIC LIABILITY AND PROPERTY DAMAGE FOR THE LIMITS AS REQUIRED BY LAW. THE CONTRACTOR SHALL BE RESPONSIBLE FOR INITIATING, MAINTAINING, AND SUPERVISING ALL SAFETY PRECAUTIONS IN CONNECTION WITH THE WORK. 19.COORDINATE ALL WORK WITH BUILDING OWNER SO AS NOT TO DISTURB OR CAUSE DAMAGE TO ANY EXISTING AREAS IN THE BUILDING. AVOID CONFLICT WITH NORMAL BUILDING OPERATIONS BY COMPLYING WITH THE BUILDING'S REGULATIONS REGARDING SCHEDULING AND USE OF ELEVATORS AND LOADING FOR DELIVERIES, HANDLING OF MATERIALS, EQUIPMENT, AND DEBRIS. 20.ANY WORK INVOLVING ALTERATIONS TO EXISTING BUILDING UTILITIES AND REQUIRING UTILITY SHUT DOWN SHALL BE COORDINATED WITH THE OWNER AND SHALL REQUIRE A MINIMUM OF (5) FIVE DAYS NOTICE. THIS WORK SHALL BE COMPLETED AT THE CONVENIENCE OF THE OWNER, ALLOWING ENOUGH TIME TO COORDINATE SCHEDULED SHUT DOWNS WITH BUILDING OCCUPANTS. 21.VERIFY IN THE FIELD THAT NO CONFLICTS EXIST WHICH WOULD PROHIBIT THE LOCATION OF ANY AND ALL MECHANICAL, TELEPHONE, DATA, ELECTRICAL, LIGHTING, PLUMBING AND SPRINKLER EQUIPMENT (TO INCLUDE ALL REQUIRED PIPING, DUCTWORK AND CONDUIT) AND THAT ALL REQUIRED CLEARANCES FOR INSTALLATION AND MAINTENANCE OF ABOVE EQUIPMENT ARE PROVIDED. 22.PROVIDE PROTECTION TO ALL EXISTING FINISHES IN ALL SPACES WITHIN OR ADJACENT TO THE SCOPE OF WORK AND THE OWNER'S SPACE. THE CONTRACTOR SHALL PATCH AND REPAIR ANY DAMAGE CAUSED BY HIM OR HIS SUBCONTRACTORS, AT CONTRACTOR'S EXPENSE. REFINISH TO MATCH EXISTING ADJACENT FINISH, OR AS NOTED HEREIN. 23.CORRECT ANY DEFECTS FOUND IN EXISTING BUILDING CONSTRUCTION WHICH AFFECT THE SCOPE OF WORK. THIS INCLUDES BUT IS NOT LIMITED TO UNEVEN SURFACES AND FINISHES AT GYPSUM BOARD OR DAMAGED FIREPROOFING. PATCH AND REPAIR SURFACES TO MATCH ADJACENT AND ADJOINING SURFACES. 24."TYPICAL" OR "TYP." MEANS IDENTICAL FOR ALL SIMILAR CONDITIONS U.O.N. 25."SIMILAR" OR "SIM" MEANS COMPARABLE CHARACTERISTICS TO THE CONDITION NOTED. VERIFY DIMENSIONS AND ORIENTATION ON PLAN. 26."VERIFY" OR "VIF" MEANS TO ASCERTAIN FIELD CONDITIONS AND CONFIRM APPLICATION WITH ARCHITECT. 27.PROVIDE STRICT CONTROL OF JOB CLEANING AND PREVENT DUST AND DEBRIS FROM MIGRATING FROM CONSTRUCTION AREA. 28.THE CONTRACTOR SHALL NOT CLOSE OR OBSTRUCT ANY STREETS, ALLEYS OR WALKS. NO MATERIAL SHALL BE PLACED OR STORED IN STREETS, ALLEYS OR WALKS. ALL DEBRIS IS TO BE REMOVED COMPLETELY FROM THE PREMISES. 29.CONTRACTOR SHALL THOROUGHLY EXAMINE THE PREMISES AND SHALL BASE HIS BID ON THE EXISTING CONDITIONS, NOTWITHSTANDING ANY INFORMATION SHOWN OR NOT INDICATED ON THE CONTRACT DOCUMENTS. 30.IT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR TO NOTIFY THE ARCHITECT OF ANY CONFLICTS HEREIN PRIOR TO THE START OF NEW WORK ON THAT ITEM OR BEAR THE RESPONSIBILITY OF CORRECTING SUCH WORK AS DIRECTED BY THE ARCHITECT. 31.ALL DRAWINGS AND WRITTEN MATERIAL HEREIN CONSTITUTE THE ORIGINAL WORK OF THE ARCHITECT, AND THE SAME MAY NOT BE DUPLICATED, USED, OR DISCLOSED WITHOUT THE WRITTEN CONSENT OF THE ARCHITECT. 32.THE ARCHITECT HAS NO RESPONSIBILITY FOR AND SHALL NOT BE HELD LIABLE FOR ANY ASBESTOS OR OTHER HAZARDOUS MATERIALS ON THE JOB SITE. ASBESTOS OR OTHER HAZARDOUS MATERIALS PRESENT AT THE JOB SITE MUST BE MITIGATED IN COMPLIANCE WITH APPLICABLE LAWS, CODES AND REGULATIONS BY THE OWNER. 33.CONTRACTOR SHALL SUBMIT A DETAILED PROJECT SCHEDULE. CONTRACTOR IS SOLELY RESPONSIBLE FOR CONSTRUCTION SEQUENCING, METHODS AND TECHNIQUES. 34.AS REQUIRED BY CODE, EACH CONTRACTOR AND EACH SUBCONTRACTOR SHALL OBTAIN REQUIRED INSPECTION OF THAT PORTION OF WORK. 35.THE CONTRACTOR SHALL CONFIRM AND SUBMIT ALL LEAD TIMES AND PROCUREMENT ISSUES FOR ALL MATERIALS INCLUDED IN THE DRAWINGS AND SPECIFICATIONS OR NECESSARY FOR THE COMPLETION OF THE WORK WITHIN TWO (2) WEEKS OF THE CONTRACT AWARD OR NOTICE TO PROCEED, WHICHEVER IS EARLIER. 36.THE CONTRACTOR SHALL AWARD ALL SUBCONTRACTS AND ENSURE THAT ALL SUBMITTALS ARE MADE WELL IN ADVANCE OF THE LEAD TIMES NECESSARY TO OBTAIN ALL MATERIALS. THE CONTRACTOR SHALL STRUCTURE THEIR SUBMITTAL SCHEDULE TO ALLOW FOR TWO REVISIONS OF EACH SUBMITTAL, ALLOWING THE ARCHITECT TEN (10) BUSINESS DAYS FOR EACH REVIEW. 37.PRODUCT SUBSTITUTIONS WILL NOT BE ALLOWED DUE TO CONTRACTOR'S FAILURE TO AWARD SUBCONTRACTS, MAKE SUBMITTALS, OR ORDER MATERIALS IN A TIMELY MANNER. IN THE EVENT THAT SUCH A FAILURE BY THE CONTRACTOR RESULTS IN A SCHEDULE DELAY, THE CONTRACTOR SHALL ACCELERATE THE SCHEDULE AT THEIR OWN EXPENSE TO MAINTAIN THE SCHEDULED COMPLETION DATE.

GENERAL NOTES

1. ALL WORK UNDER THIS CONTRACT SHALL BE GOVERNED BY AIA DOCUMENT A201, GENERAL CONDITIONS OF THE CONTRACT, LATEST EDITION. IF ANY CONFLICTS BETWEEN THESE DRAWINGS AND DOCUMENT A201 ARISE, THE MORE STRINGENT OF THE TWO REQUIREMENTS SHALL APPLY. 2. THE INTENT OF THE CONTRACT DOCUMENTS IS TO ALLOW FOR THE PERFORMANCE OF THE WORK. EVERY ITEM NECESSARILY REQUIRED MAY NOT BE SPECIFICALLY MENTIONED OR SHOWN. UNLESS OTHERWISE INDICATED IN THE CONSTRUCTION DOCUMENTS AS BEING NOT IN CONTRACT (N.I.C., NIC) OR EXISTING, ALL SYSTEMS AND EQUIPMENT SHALL BE COMPLETED AND APPROPRIATELY OPERABLE. FURNISH AND INSTALL ALL SPECIFIED AND APPROPRIATE ITEMS, AND ALL INCIDENTAL, ACCESSORY, AND OTHER ITEMS NOT SPECIFIED BUT REQUIRED FOR A COMPLETE AND FINISHED ASSEMBLY. 3. NO WORK DEFECTIVE IN WORKMANSHIP OR QUALITY OR DEFICIENT IN ANY REQUIREMENTS OF THE CONTRACT DOCUMENTS WILL BE ACCEPTABLE, WHETHER OR NOT THE ARCHITECT DISCOVERS OR POINTS OUT DEFECTS OR DEFICIENCIES DURING CONSTRUCTION. DEFECTIVE WORK REVEALED WITHIN THE TIME REQUIRED BY WARRANTEES SHALL BE REPLACED BY WORK CONFORMING WITH THE INTENT OF THE CONTRACT. NO PAYMENT, EITHER PARTIAL OR FINAL, SHALL BE CONSTRUED AS AN ACCEPTANCE OF DEFECTIVE WORK OR IMPROPER MATERIALS. 4. IT IS INTENDED THAT THE CONTRACTOR PROVIDE A COMPLETE JOB AND ANY OMISSIONS IN THESE NOTES OR IN THE OUTLINE OF WORK SHALL NOT BE CONSTRUED AS RELIEVING THE CONTRACTOR OF SUCH RESPONSIBILITIES IMPLIED BY THE SCOPE OF WORK, EXCEPT FOR ITEMS SPECIFICALLY NOTED. 5. SHOULD ANY PORTION OF THE CONTRACT DOCUMENTS PROVE TO BE UNENFORCEABLE FOR WHATEVER REASON, SUCH UNENFORCEABILITY SHALL NOT EXTEND TO THE REMAINDER OF THE CONTRACT NOR SHALL IT VOID ANY OTHER PROVISIONS OF THE CONTRACT. 6. THROUGHOUT THE DURATION OF THE PROJECT, THE CONTRACTOR SHALL REFRAIN FROM ACTIONS THAT COULD LEAD TO THE FILING OF CLAIMS OF LIEN BY SUBCONTRACTORS, SUPPLIERS OF MATERIALS, LABOR, SERVICE, EQUIPMENT OR ANY OTHER INDIVIDUAL OR COMPANY SO ENTITLED UNDER GOVERNING LAWS AND REGULATIONS UNLESS REASONABLE AND JUSTIFIABLE CAUSE CAN BE SHOWN. APPROVAL FOR PAYMENT SHALL BE CONTINGENT UPON THE CONTRACTOR'S OBTAINING AND FURNISHING TO THE OWNER SIGNED RELEASES FROM SUCH INDIVIDUALS OR COMPANIES. 7. THE CONTRACTOR IS RESPONSIBLE FOR CHECKING CONTRACT DOCUMENTS, FIELD CONDITIONS AND DIMENSIONS FOR ACCURACY AND CONFIRMING THAT WORK IS BUILDABLE AS SHOWN BEFORE PROCEEDING WITH CONSTRUCTION. IF THERE ARE ANY QUESTIONS REGARDING THESE OR OTHER COORDINATION ISSUES, THE CONTRACTOR SHALL SUBMIT THEM, IN WRITING, TO THE ARCHITECT AND IS RESPONSIBLE FOR OBTAINING A WRITTEN CLARIFICATION FROM THE ARCHITECT BEFORE PROCEEDING WITH WORK IN QUESTION, OR RELATED WORK. 8. IN THE EVENT OF DISCREPANCIES BETWEEN ANY DRAWINGS AND/OR SPECIFICATIONS, THE MORE COSTLY AND/OR MORE RESTRICTIVE CONDITION SHALL BE DEEMED THE CONTRACT REQUIREMENT, UNLESS OTHERWISE STATED IN WRITING FROM THE OWNER. 9. EXECUTE WORK IN ACCORDANCE WITH ANY AND ALL APPLICABLE LOCAL, STATE, AND FEDERAL CODES, MANUFACTURER'S RECOMMENDATIONS, TRADE AND REFERENCED STANDARDS INCLUDING BUT NOT LIMITED TO: NEC, NFPA, ASTM, ASHRAE, LATEST ADOPTED EDITIONS. THESE SHALL SUPERSEDE DRAWINGS, NOTES AND DIMENSIONS IN ALL CASES. THE ARCHITECT SHALL BE NOTIFIED OF SUCH CHANGES BEFORE WORK IS STARTED. OBTAIN PERMITS BEFORE STARTING WORK, AND OBTAIN APPROVALS OF ALL REGULATORY AGENCIES UPON COMPLETION, AND AS REQUIRED. 10.THE GENERAL CONTRACTOR IS RESPONSIBLE FOR PAYING FOR AND OBTAINING ALL PERMITS, INSPECTIONS, REQUIRED TESTS AND UTILITY CONNECTIONS UNLESS OTHERWISE NOTED. 11.DO NOT SCALE DRAWINGS; DIMENSIONS SHALL GOVERN. DETAILS SHALL GOVERN OVER PLANS AND ELEVATIONS. LARGE SCALE DETAILS SHALL GOVERN OVER SMALL SCALE DETAILS. WRITTEN SPECIFICATIONS SHALL GOVERN OVER ALL. 12.CLARIFY ALL DISCREPANCIES AND QUESTIONS RELATIVE TO CONSTRUCTION DOCUMENTS, SPECIFICATIONS, AND FIELD CONDITIONS PRIOR TO SUBMITTING BIDS OR COMMENCING WORK. BY SUBMITTING THEIR BID, THE CONTRACTOR ATTESTS THAT THEY HAVE NO OPEN QUESTIONS RELATED TO THE CONSTRUCTION DOCUMENTS AND IS THEREFORE NOT ENTITLED TO ADDITIONAL COMPENSATION RELATED TO ANY ITEMS THEY DEEM TO BE UNCLEAR. 13.THERE SHALL BE NO SUBSTITUTION OF MATERIAL WHERE A MANUFACTURER IS SPECIFIED. WHERE THE TERM "OR EQUAL" IS USED, THE ARCHITECT ALONE SHALL DETERMINE EQUALITY BASED UPON INFORMATION SUBMITTED BY THE CONTRACTOR. 14.THE CONTRACTOR SHALL BE RESPONSIBLE FOR THE DISTRIBUTION OF DRAWINGS TO ALL TRADES UNDER THEIR JURISDICTION OR AUTHORITY. 15.DO NOT PROCEED WITH ANY WORK REQUIRING ADDITIONAL COMPENSATION BEYOND THE CONTRACT AMOUNT WITHOUT WRITTEN AUTHORIZATION FROM THE OWNER. FAILURE TO OBTAIN AUTHORIZATION SHALL INVALIDATE ANY CLAIM FOR EXTRA COMPENSATION. 16.ALL INSTALLED PLUMBING, MECHANICAL, AND ELECTRICAL EQUIPMENT SHALL OPERATE QUIETLY AND FREE OF VIBRATION. 17.ALL MATERIALS SHALL BE NEW, UNUSED, AND OF THE HIGHEST QUALITY IN EVERY RESPECT UNLESS OTHERWISE NOTED. MANUFACTURED MATERIALS AND EQUIPMENT SHALL BE INSTALLED AS PER MANUFACTURER'S RECOMMENDATIONS AND INSTRUCTIONS, U.O.N. 18.THE CONTRACTOR AND SUBCONTRACTORS SHALL PURCHASE AND MAINTAIN CERTIFICATIONS OF INSURANCE WITH RESPECT TO WORKERS COMPENSATION, PUBLIC LIABILITY AND PROPERTY DAMAGE FOR THE LIMITS AS REQUIRED BY LAW. THE CONTRACTOR SHALL BE RESPONSIBLE FOR INITIATING, MAINTAINING, AND SUPERVISING ALL SAFETY PRECAUTIONS IN CONNECTION WITH THE WORK. 19.COORDINATE ALL WORK WITH BUILDING OWNER SO AS NOT TO DISTURB OR CAUSE DAMAGE TO ANY EXISTING AREAS IN THE BUILDING. AVOID CONFLICT WITH NORMAL BUILDING OPERATIONS BY COMPLYING WITH THE BUILDING'S REGULATIONS REGARDING SCHEDULING AND USE OF ELEVATORS AND LOADING FOR DELIVERIES, HANDLING OF MATERIALS, EQUIPMENT, AND DEBRIS. 20.ANY WORK INVOLVING ALTERATIONS TO EXISTING BUILDING UTILITIES AND REQUIRING UTILITY SHUT DOWN SHALL BE COORDINATED WITH THE OWNER AND SHALL REQUIRE A MINIMUM OF (5) FIVE DAYS NOTICE. THIS WORK SHALL BE COMPLETED AT THE CONVENIENCE OF THE OWNER, ALLOWING ENOUGH TIME TO COORDINATE SCHEDULED SHUT DOWNS WITH BUILDING OCCUPANTS. 21.VERIFY IN THE FIELD THAT NO CONFLICTS EXIST WHICH WOULD PROHIBIT THE LOCATION OF ANY AND ALL MECHANICAL, TELEPHONE, DATA, ELECTRICAL, LIGHTING, PLUMBING AND SPRINKLER EQUIPMENT (TO INCLUDE ALL REQUIRED PIPING, DUCTWORK AND CONDUIT) AND THAT ALL REQUIRED CLEARANCES FOR INSTALLATION AND MAINTENANCE OF ABOVE EQUIPMENT ARE PROVIDED. 22.PROVIDE PROTECTION TO ALL EXISTING FINISHES IN ALL SPACES WITHIN OR ADJACENT TO THE SCOPE OF WORK AND THE OWNER'S SPACE. THE CONTRACTOR SHALL PATCH AND REPAIR ANY DAMAGE CAUSED BY HIM OR HIS SUBCONTRACTORS, AT CONTRACTOR'S EXPENSE. REFINISH TO MATCH EXISTING ADJACENT FINISH, OR AS NOTED HEREIN. 23.CORRECT ANY DEFECTS FOUND IN EXISTING BUILDING CONSTRUCTION WHICH AFFECT THE SCOPE OF WORK. THIS INCLUDES BUT IS NOT LIMITED TO UNEVEN SURFACES AND FINISHES AT GYPSUM BOARD OR DAMAGED FIREPROOFING. PATCH AND REPAIR SURFACES TO MATCH ADJACENT AND ADJOINING SURFACES. 24."TYPICAL" OR "TYP." MEANS IDENTICAL FOR ALL SIMILAR CONDITIONS U.O.N. 25."SIMILAR" OR "SIM" MEANS COMPARABLE CHARACTERISTICS TO THE CONDITION NOTED. VERIFY DIMENSIONS AND ORIENTATION ON PLAN. 26."VERIFY" OR "VIF" MEANS TO ASCERTAIN FIELD CONDITIONS AND CONFIRM APPLICATION WITH ARCHITECT. 27.PROVIDE STRICT CONTROL OF JOB CLEANING AND PREVENT DUST AND DEBRIS FROM MIGRATING FROM CONSTRUCTION AREA. 28.THE CONTRACTOR SHALL NOT CLOSE OR OBSTRUCT ANY STREETS, ALLEYS OR WALKS. NO MATERIAL SHALL BE PLACED OR STORED IN STREETS, ALLEYS OR WALKS. ALL DEBRIS IS TO BE REMOVED COMPLETELY FROM THE PREMISES. 29.CONTRACTOR SHALL THOROUGHLY EXAMINE THE PREMISES AND SHALL BASE HIS BID ON THE EXISTING CONDITIONS, NOTWITHSTANDING ANY INFORMATION SHOWN OR NOT INDICATED ON THE CONTRACT DOCUMENTS. 30.IT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR TO NOTIFY THE ARCHITECT OF ANY CONFLICTS HEREIN PRIOR TO THE START OF NEW WORK ON THAT ITEM OR BEAR THE RESPONSIBILITY OF CORRECTING SUCH WORK AS DIRECTED BY THE ARCHITECT. 31.ALL DRAWINGS AND WRITTEN MATERIAL HEREIN CONSTITUTE THE ORIGINAL WORK OF THE ARCHITECT, AND THE SAME MAY NOT BE DUPLICATED, USED, OR DISCLOSED WITHOUT THE WRITTEN CONSENT OF THE ARCHITECT. 32.THE ARCHITECT HAS NO RESPONSIBILITY FOR AND SHALL NOT BE HELD LIABLE FOR ANY ASBESTOS OR OTHER HAZARDOUS MATERIALS ON THE JOB SITE. ASBESTOS OR OTHER HAZARDOUS MATERIALS PRESENT AT THE JOB SITE MUST BE MITIGATED IN COMPLIANCE WITH APPLICABLE LAWS, CODES AND REGULATIONS BY THE OWNER. 33.CONTRACTOR SHALL SUBMIT A DETAILED PROJECT SCHEDULE. CONTRACTOR IS SOLELY RESPONSIBLE FOR CONSTRUCTION SEQUENCING, METHODS AND TECHNIQUES. 34.AS REQUIRED BY CODE, EACH CONTRACTOR AND EACH SUBCONTRACTOR SHALL OBTAIN REQUIRED INSPECTION OF THAT PORTION OF WORK. 35.THE CONTRACTOR SHALL CONFIRM AND SUBMIT ALL LEAD TIMES AND PROCUREMENT ISSUES FOR ALL MATERIALS INCLUDED IN THE DRAWINGS AND SPECIFICATIONS OR NECESSARY FOR THE COMPLETION OF THE WORK WITHIN TWO (2) WEEKS OF THE CONTRACT AWARD OR NOTICE TO PROCEED, WHICHEVER IS EARLIER. 36.THE CONTRACTOR SHALL AWARD ALL SUBCONTRACTS AND ENSURE THAT ALL SUBMITTALS ARE MADE WELL IN ADVANCE OF THE LEAD TIMES NECESSARY TO OBTAIN ALL MATERIALS. THE CONTRACTOR SHALL STRUCTURE THEIR SUBMITTAL SCHEDULE TO ALLOW FOR TWO REVISIONS OF EACH SUBMITTAL, ALLOWING THE ARCHITECT TEN (10) BUSINESS DAYS FOR EACH REVIEW. 37.PRODUCT SUBSTITUTIONS WILL NOT BE ALLOWED DUE TO CONTRACTOR'S FAILURE TO AWARD SUBCONTRACTS, MAKE SUBMITTALS, OR ORDER MATERIALS IN A TIMELY MANNER. IN THE EVENT THAT SUCH A FAILURE BY THE CONTRACTOR RESULTS IN A SCHEDULE DELAY, THE CONTRACTOR SHALL ACCELERATE THE SCHEDULE AT THEIR OWN EXPENSE TO MAINTAIN THE SCHEDULED COMPLETION DATE.

DEFINITIONS
"OWNER" OR "LANDLORD" REFERS TO THE ENTITY NOTED ON THE DRAWING COVER SHEET AS
"CLIENT"
"ARCHITECT" REFERS TO NORR DESIGN, INC.
"BIDDER" REFERS TO PERSON OR ENTITY WHO SUBMITS A BID AS A GENERAL CONTRACTOR.

1.
	COORDINATE SUBMITTALS FOR RELATED WORK SO THAT ITEMS WHICH MUST BE COORDINATED, SUC
	AS COLORS OF FINISHES, MAY BE REVIEWED TOGETHER.
2.
	VERIFY ACCURACY OF CONTENTS. AT A MINIMUM, VERIFY: MATERIALS, FIELD DIMENSIONS, ADJACEN
	CONSTRUCTION, CONFORMANCE WITH SPECIFIED ENVIRONMENTAL AND JOB CONDITIONS,
	COORDINATION WITH OTHER WORK, AND CONFORMANCE WITH THE CONTRACT DOCUMENTS.
3.	THE CONTRACTOR IS TO REVIEW, STAMP AND SIGN EACH SUBMITTAL TO ATTEST THAT IT HAS BEEN
	REVIEWED BY THE CONTRACTOR, AND TRANSMIT TO THE ARCHITECT AND OWNER. THE CONTRACTO
	SHALL ELECTRONICALLY TRANSMIT A PDF WITH A LETTER OF TRANSMITTAL. TRANSMITTALS WILL NO
	BE ACCEPTED VIA FACSIMILE MACHINE. PROVIDE CLEARLY READABLE COPIES. DO NOT SUBMIT COPI
	WHICH ARE MULTIPLE-GENERATION PHOTOCOPIES OR FACSIMILE COPIES UNLESS TEXT AND DIAGRA
	ARE CLEAR AND PLAINLY READABLE.
4.	THE CONTRACTOR IS TO SUBMIT SHOP DRAWINGS AS FOLLOWS: PREPARE SHOP DRAWINGS SPECIFI
	TO THIS PROJECT TO DESCRIBE THE FABRICATION AND INSTALLATION OF PRODUCTS;
	MANUFACTURER'S PREPRINTED STANDARD DETAILS ARE NOT SHOP DRAWINGS. DRAW CLEARLY AN
	PRESENT COMPLETE INFORMATION. INCLUDE PLANS, ELEVATIONS AND LARGE SCALE DETAILS, AS APPROPRIATE TO THE WORK SHOWN. NOTE FIELD DIMENSIONS AND ADJACENT CONSTRUCTION.
	INCLUDE SCHEDULES, PATTERNS, CALCULATIONS AND INSTRUCTIONS REGARDING COORDINATION A
	INSTALLATION AS REQUIRED. IDENTIFY DETAILS BY REFERENCE TO CONTRACT DRAWING SHEET AN
	DETAIL, SCHEDULE, ROOM NUMBER, DOOR NUMBER OR OTHER APPLICABLE IDENTIFICATION.
5.
	PERFORMANCE CHARACTERISTICS AND CAPACITIES. SHOW DIMENSIONS AND CLEARANCES REQUIRE
	SHOW WIRING OR PIPING DIAGRAMS AND CONTROLS. SHOW DIMENSIONS AND CLEARANCES REQUIR
	FOR PROPER OPERATION AND MAINTENANCE. SHOP DRAWINGS AND ARCHITECT'S REVIEW WILL BE
	SENT BACK ELECTRONICALLY. CONTRACTOR TO PRINT AND DISTRIBUTE COPIES TO
	SUBCONTRACTORS.
6.	THE CONTRACTOR IS TO SUBMIT SAMPLES AS FOLLOWS: PROVIDE SAMPLES OF ADEQUATE SIZE TO
	PERMIT PROPER EVALUATION OF MATERIAL. WHERE VARIATIONS IN COLOR OR IN OTHER
	UNLESS OTHERWISE SPECIFIED IN THE SECTION REQUIRING THE SAMPLES.
7.	PROVIDE CERTIFICATIONS, QUALIFICATION STATEMENTS, TEST REPORTS AND SIMILAR SUBMITTALS
	WHERE SPECIFIED FOR SUBMITTALS, QUALITY ASSURANCE, OR QUALITY CONTROL.
8.	THE ARCHITECT AND BUILDING OWNER WILL REVIEW SUBMITTALS AS FOLLOWS: THE ARCHITECT AN
	BUILDING OWNER WILL REVIEW ONLY THOSE SUBMITTALS EXPLICITLY REQUIRED BY THE CONTRACT
	DOCUMENTS OR REQUESTED BY THE ARCHITECT AS THE WORK PROCEEDS. THE ARCHITECT WILL
	STAMP EACH SUBMITTAL TO INDICATE THE ACTION TAKEN. FABRICATION OR INSTALLATION OF WORK
	FOR WHICH ARCHITECT'S REVIEW IS REQUIRED SHOULD NOT BEGIN UNTIL THE SUBMITTAL IS
	FABRICATION AND INSTALLATION.
9.	RESUBMISSION: IF SUBMITTAL IS STAMPED "REVISE AND RESUBMIT", MAKE CORRECTIONS OR CHANG
	REQUIRED BY THE ARCHITECT IN THE SUBMITTALS AND RESUBMIT UNTIL ACCEPTED. IF SUBMITTAL I
	STAMPED "REJECTED", RESUBMIT IN CONFORMANCE WITH THE CONTRACT DOCUMENTS. IN
	RESUBMITTING, COMPLY WITH REQUIREMENTS SPECIFIED FOR THE INITIAL SUBMITTAL. TRANSMIT EA
	RESUBMITTAL WITH A NEW LETTER OF TRANSMITTAL AND NOTE THE TRANSMITTAL NUMBER OF THE
	FIRST SUBMISSION ON THE TRANSMITTAL FORM.
10.
	*	MILLWORK
	*	LIGHT FIXTURES
	*	CEILING SYSTEMS

1.	ALL WORK UNDER THIS CONTRACT SHALL BE GOVERNED BY AIA DOCUMENT A201, GENERAL
	CONDITIONS OF THE CONTRACT, LATEST EDITION. IF ANY CONFLICTS BETWEEN THESE DRAWINGS A
	DOCUMENT A201 ARISE, THE MORE STRINGENT OF THE TWO REQUIREMENTS SHALL APPLY.
2.	THE INTENT OF THE CONTRACT DOCUMENTS IS TO ALLOW FOR THE PERFORMANCE OF THE WORK.
	EVERY ITEM NECESSARILY REQUIRED MAY NOT BE SPECIFICALLY MENTIONED OR SHOWN. UNLESS
	OTHERWISE INDICATED IN THE CONSTRUCTION DOCUMENTS AS BEING NOT IN CONTRACT (N.I.C., NIC
	OR EXISTING, ALL SYSTEMS AND EQUIPMENT SHALL BE COMPLETED AND APPROPRIATELY OPERABL
	FURNISH AND INSTALL ALL SPECIFIED AND APPROPRIATE ITEMS, AND ALL INCIDENTAL, ACCESSORY,
	AND OTHER ITEMS NOT SPECIFIED BUT REQUIRED FOR A COMPLETE AND FINISHED ASSEMBLY.
3.	NO WORK DEFECTIVE IN WORKMANSHIP OR QUALITY OR DEFICIENT IN ANY REQUIREMENTS OF THE
	CONTRACT DOCUMENTS WILL BE ACCEPTABLE, WHETHER OR NOT THE ARCHITECT DISCOVERS OR
	POINTS OUT DEFECTS OR DEFICIENCIES DURING CONSTRUCTION. DEFECTIVE WORK REVEALED WIT
	THE TIME REQUIRED BY WARRANTEES SHALL BE REPLACED BY WORK CONFORMING WITH THE INTEN
	OF THE CONTRACT. NO PAYMENT, EITHER PARTIAL OR FINAL, SHALL BE CONSTRUED AS AN
	ACCEPTANCE OF DEFECTIVE WORK OR IMPROPER MATERIALS.
4.
	NOTES OR IN THE OUTLINE OF WORK SHALL NOT BE CONSTRUED AS RELIEVING THE CONTRACTOR O
	SUCH RESPONSIBILITIES IMPLIED BY THE SCOPE OF WORK, EXCEPT FOR ITEMS SPECIFICALLY NOTE
5.
	CONTRACT NOR SHALL IT VOID ANY OTHER PROVISIONS OF THE CONTRACT.
6.	THROUGHOUT THE DURATION OF THE PROJECT, THE CONTRACTOR SHALL REFRAIN FROM ACTIONS
	THAT COULD LEAD TO THE FILING OF CLAIMS OF LIEN BY SUBCONTRACTORS, SUPPLIERS OF
	UNDER GOVERNING LAWS AND REGULATIONS UNLESS REASONABLE AND JUSTIFIABLE CAUSE CAN B
	SHOWN. APPROVAL FOR PAYMENT SHALL BE CONTINGENT UPON THE CONTRACTOR'S OBTAINING AN
	FURNISHING TO THE OWNER SIGNED RELEASES FROM SUCH INDIVIDUALS OR COMPANIES.
7.	THE CONTRACTOR IS RESPONSIBLE FOR CHECKING CONTRACT DOCUMENTS, FIELD CONDITIONS AN
	DIMENSIONS FOR ACCURACY AND CONFIRMING THAT WORK IS BUILDABLE AS SHOWN BEFORE
	PROCEEDING WITH CONSTRUCTION. IF THERE ARE ANY QUESTIONS REGARDING THESE OR OTHER
	COORDINATION ISSUES, THE CONTRACTOR SHALL SUBMIT THEM, IN WRITING, TO THE ARCHITECT AN
	IS RESPONSIBLE FOR OBTAINING A WRITTEN CLARIFICATION FROM THE ARCHITECT BEFORE
	PROCEEDING WITH WORK IN QUESTION, OR RELATED WORK.
8.
	COSTLY AND/OR MORE RESTRICTIVE CONDITION SHALL BE DEEMED THE CONTRACT REQUIREMENT,
	UNLESS OTHERWISE STATED IN WRITING FROM THE OWNER.
9.	EXECUTE WORK IN ACCORDANCE WITH ANY AND ALL APPLICABLE LOCAL, STATE, AND FEDERAL COD
	MANUFACTURER'S RECOMMENDATIONS, TRADE AND REFERENCED STANDARDS INCLUDING BUT NOT
	LIMITED TO: NEC, NFPA, ASTM, ASHRAE, LATEST ADOPTED EDITIONS. THESE SHALL
	APPROVALS OF ALL REGULATORY AGENCIES UPON COMPLETION, AND AS REQUIRED.
10.
	INSPECTIONS, REQUIRED TESTS AND UTILITY CONNECTIONS UNLESS OTHERWISE NOTED.
11.	DO NOT SCALE DRAWINGS; DIMENSIONS SHALL GOVERN. DETAILS SHALL GOVERN OVER PLANS AND
	ELEVATIONS. LARGE SCALE DETAILS SHALL GOVERN OVER SMALL SCALE DETAILS. WRITTEN
	SPECIFICATIONS SHALL GOVERN OVER ALL.
12.	CLARIFY ALL DISCREPANCIES AND QUESTIONS RELATIVE TO CONSTRUCTION DOCUMENTS,
	SPECIFICATIONS, AND FIELD CONDITIONS PRIOR TO SUBMITTING BIDS OR COMMENCING WORK. BY
	SUBMITTING THEIR BID, THE CONTRACTOR ATTESTS THAT THEY HAVE NO OPEN QUESTIONS RELATE
	TO THE CONSTRUCTION DOCUMENTS AND IS THEREFORE NOT ENTITLED TO ADDITIONAL
	COMPENSATION RELATED TO ANY ITEMS THEY DEEM TO BE UNCLEAR.
13.	THERE SHALL BE NO SUBSTITUTION OF MATERIAL WHERE A MANUFACTURER IS SPECIFIED. WHERE
	THE TERM "OR EQUAL" IS USED, THE ARCHITECT ALONE SHALL DETERMINE EQUALITY BASED UPON
	INFORMATION SUBMITTED BY THE CONTRACTOR.
14.	THE CONTRACTOR SHALL BE RESPONSIBLE FOR THE DISTRIBUTION OF DRAWINGS TO ALL TRADES
	UNDER THEIR JURISDICTION OR AUTHORITY
15.	DO NOT PROCEED WITH ANY WORK REQUIRING ADDITIONAL COMPENSATION BEYOND THE CONTRAC
	AMOUNT WITHOUT WRITTEN AUTHORIZATION FROM THE OWNER. FAILURE TO OBTAIN AUTHORIZATIO
	SHALL INVALIDATE ANY CLAIM FOR EXTRA COMPENSATION.
16.	ALL INSTALLED PLUMBING, MECHANICAL, AND ELECTRICAL EQUIPMENT SHALL OPERATE QUIETLY AN
	FREE OF VIBRATION.
17.	ALL MATERIALS SHALL BE NEW, UNUSED, AND OF	THE HIGHEST QUALITY IN EVERY RESPECT UNLES
	MANUFACTURER'S RECOMMENDATIONS AND INSTRUCTIONS, U.O.N.
18.
	INSURANCE WITH RESPECT TO WORKERS COMPENSATION, PUBLIC LIABILITY AND PROPERTY DAMAG
	FOR THE LIMITS AS REQUIRED BY LAW. THE CONTRACTOR SHALL BE RESPONSIBLE FOR INITIATING,
	MAINTAINING, AND SUPERVISING ALL SAFETY PRECAUTIONS IN CONNECTION WITH THE WORK.
19.	COORDINATE ALL WORK WITH BUILDING OWNER SO AS NOT TO DISTURB OR CAUSE DAMAGE TO ANY
	EXISTING AREAS IN THE BUILDING. AVOID CONFLICT WITH NORMAL BUILDING OPERATIONS BY
	COMPLYING WITH THE BUILDING'S REGULATIONS REGARDING SCHEDULING AND USE OF ELEVATORS
	AND LOADING FOR DELIVERIES, HANDLING OF MATERIALS, EQUIPMENT, AND DEBRIS.
20.	ANY WORK INVOLVING ALTERATIONS TO EXISTING BUILDING UTILITIES AND REQUIRING UTILITY SHUT
	DOWN SHALL BE COORDINATED WITH THE OWNER AND SHALL REQUIRE A MINIMUM OF (5) FIVE DAYS
	NOTICE. THIS WORK SHALL BE COMPLETED AT THE CONVENIENCE OF THE OWNER, ALLOWING ENOU
	TIME TO COORDINATE SCHEDULED SHUT DOWNS WITH BUILDING OCCUPANTS.
21.	VERIFY IN THE FIELD THAT NO CONFLICTS EXIST WHICH WOULD PROHIBIT THE LOCATION OF ANY AN
	ALL MECHANICAL, TELEPHONE, DATA, ELECTRICAL, LIGHTING, PLUMBING AND SPRINKLER EQUIPMEN
	(TO INCLUDE ALL REQUIRED PIPING, DUCTWORK AND CONDUIT) AND THAT ALL REQUIRED CLEARANC
	FOR INSTALLATION AND MAINTENANCE OF ABOVE EQUIPMENT ARE PROVIDED.
22.	PROVIDE PROTECTION TO ALL EXISTING FINISHES IN ALL SPACES WITHIN OR ADJACENT TO THE SCO
	EXISTING ADJACENT FINISH, OR AS NOTED HEREIN.
23.	CORRECT ANY DEFECTS FOUND IN EXISTING BUILDING CONSTRUCTION WHICH AFFECT THE SCOPE
	WORK. THIS INCLUDES BUT IS NOT LIMITED TO UNEVEN SURFACES AND FINISHES AT GYPSUM BOARD
	OR DAMAGED FIREPROOFING. PATCH AND REPAIR SURFACES TO MATCH ADJACENT AND ADJOINING
	SURFACES.
24.	"TYPICAL" OR "TYP." MEANS IDENTICAL FOR ALL SIMILAR CONDITIONS U.O.N.
25.
	DIMENSIONS AND ORIENTATION ON PLAN.
26.
	ARCHITECT.
27.
	FROM CONSTRUCTION AREA.
28.	THE CONTRACTOR SHALL NOT CLOSE OR OBSTRUCT ANY STREETS, ALLEYS OR WALKS. NO MATERIA
	COMPLETELY FROM THE PREMISES.
29.
	CONTRACT DOCUMENTS.
30.	IT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR TO NOTIFY THE ARCHITECT OF ANY CONFLI
	CORRECTING SUCH WORK AS DIRECTED BY THE ARCHITECT.
31.	ALL DRAWINGS AND WRITTEN MATERIAL HEREIN CONSTITUTE THE ORIGINAL WORK OF THE
	ARCHITECT, AND THE SAME MAY NOT BE DUPLICATED, USED, OR DISCLOSED WITHOUT THE WRITTEN
	CONSENT OF THE ARCHITECT.
32.	THE ARCHITECT HAS NO RESPONSIBILITY FOR AND SHALL NOT BE HELD LIABLE FOR ANY ASBESTOS
	OTHER HAZARDOUS MATERIALS ON THE JOB SITE. ASBESTOS OR OTHER HAZARDOUS MATERIALS
	PRESENT AT THE JOB SITE MUST BE MITIGATED IN COMPLIANCE WITH APPLICABLE LAWS, CODES AN
	REGULATIONS BY THE OWNER.
33.	CONTRACTOR SHALL SUBMIT A DETAILED PROJECT SCHEDULE. CONTRACTOR IS SOLELY RESPONSI
	FOR CONSTRUCTION SEQUENCING, METHODS AND TECHNIQUES.
34.	AS REQUIRED BY CODE, EACH CONTRACTOR AND EACH SUBCONTRACTOR SHALL OBTAIN REQUIRED
	INSPECTION OF THAT PORTION OF WORK.
35.	THE CONTRACTOR SHALL CONFIRM AND SUBMIT ALL LEAD TIMES AND PROCUREMENT ISSUES FOR A
	MATERIALS INCLUDED IN THE DRAWINGS AND SPECIFICATIONS OR NECESSARY FOR THE COMPLETIO
	OF THE WORK WITHIN TWO (2) WEEKS OF THE CONTRACT AWARD OR NOTICE TO PROCEED,
	WHICHEVER IS EARLIER.
36.	THE CONTRACTOR SHALL AWARD ALL SUBCONTRACTS AND ENSURE THAT ALL SUBMITTALS ARE MA
	WELL IN ADVANCE OF THE LEAD TIMES NECESSARY TO OBTAIN ALL MATERIALS. THE CONTRACTOR
	SHALL STRUCTURE THEIR SUBMITTAL SCHEDULE TO ALLOW FOR TWO REVISIONS OF EACH SUBMITT
	ALLOWING THE ARCHITECT TEN (10) BUSINESS DAYS FOR EACH REVIEW.
37.
	SUBCONTRACTS, MAKE SUBMITTALS, OR ORDER MATERIALS IN A TIMELY MANNER. IN THE EVENT TH
	SUCH A FAILURE BY THE CONTRACTOR RESULTS IN A SCHEDULE DELAY, THE CONTRACTOR SHALL
	ACCELERATE THE SCHEDULE AT THEIR OWN EXPENSE TO MAINTAIN THE SCHEDULED COMPLETION
	DATE.

1.	BIDDER SHALL CAREFULLY STUDY AND COMPARE BIDDING DOCUMENTS WITH EACH
	SUBCONTRACTOR, AND WITH OTHER WORK BEING BID CONCURRENTLY TO EXTENT THAT IT
	RELATES TO WORK FOR WHICH BID IS SUBMITTED, SHALL EXAMINE SITE AND LOCAL
	CONDITIONS, AND SHALL AT ONCE REPORT ANY ERRORS, INCONSISTENCIES OR AMBIGUITIE
	DISCOVERED, IN WRITING, TO THE ARCHITECT.
2.	IN CASE OF AN INCONSISTENCY BETWEEN DRAWINGS AND SPECIFICATIONS OR WITHIN
	EITHER DOCUMENT NOT CLARIFIED, MORE SPECIFIC PROVISION WILL TAKE PRECEDENCE
	OR GREATER QUANTITY OF WORK SHALL BE PROVIDED IN ACCORDANCE WITH ARCHITECT'S
	INTERPRETATION. ON DRAWINGS, FIGURES TAKE PRECEDENCE OVER SCALED DIMENSIONS.
	SCALING OF DIMENSIONS, IF DONE, IS DONE AT BIDDER'S OWN RISK.
3.	MATERIALS, PRODUCTS, AND EQUIPMENT DESCRIBED IN CONTRACT DOCUMENTS ESTABLISH
	STANDARD OF REQUIRED FUNCTION, DIMENSION, APPEARANCE, AND QUALITY REQUIRED
	FOR THE PROJECT.
4.	BIDDER REPRESENTS, BY SUBMISSION OF A BID, THAT BID IS BASED UPON PRODUCTS,
	EQUIPMENT AND EXECUTION OF WORK AS DESCRIBED IN CONTRACT DOCUMENTS. NO
	SUBSTITUTIONS SHALL BE ALLOWED DURING PRICING.

DRAWING NUMBER
WHERE VIEW IS LOCATED

PRINTED DATA. CLEARLY MARK EACH COPY TO IDENTIFY PERTINENT PRODUCTS OR MODELS; CROSS
OUT INFORMATION WHICH IS NOT APPLICABLE TO THE WORK AND SUPPLEMENT STANDARD

DRAWING NUMBER
WHERE SECTION IS LOCATED

MATERIALS AND EQUIPMENT
1. LOCATE REQUIRED LABELS AND STAMPS WHERE REQUIRED FOR OBSERVATION AFTER INSTALLATION ON AN ACCESSIBLE SURFACE WHICH, IN OCCUPIED SPACES, IS NOT CONSPICUOUS. 2. EXCEPT AS OTHERWISE INDICATED FOR REQUIRED LABELS, DO NOT PERMANENTLY ATTACH OR IMPRINT MANUFACTURER'S OR PRODUCER'S NAMEPLATES OR TRADEMARKS ON EXPOSED SURFACES OF PRODUCTS WHICH WILL BE EXPOSED TO VIEW. 3. TRANSPORT PRODUCTS BY METHODS TO AVOID PRODUCT DAMAGE. DELIVER PRODUCTS IN UNDAMAGED CONDITION IN MANUFACTURER'S UNOPENED CONTAINERS. 4. PROVIDE EQUIPMENT AND PERSONNEL TO HANDLE PRODUCTS BY METHODS TO PREVENT DAMAGE. 5. PROMPTLY INSPECT SHIPMENTS TO ASSURE THAT PRODUCTS COMPLY WITH REQUIREMENTS, QUANTITIES ARE CORRECT, AND PRODUCTS ARE UNDAMAGED. 6. STORE PRODUCTS IN ACCORDANCE WITH MANUFACTURER'S INSTRUCTIONS, WITH SEALS AND LABELS INTACT AND LEGIBLE. STORE SENSITIVE PRODUCTS IN ENCLOSURES; MAINTAIN TEMPERATURE AND HUMIDITY RANGES RECOMMENDED BY MANUFACTURER.

MATERIALS AND EQUIPMENT

1. LOCATE REQUIRED LABELS AND STAMPS WHERE REQUIRED FOR OBSERVATION AFTER INSTALLATION ON AN ACCESSIBLE SURFACE WHICH, IN OCCUPIED SPACES, IS NOT CONSPICUOUS. 2. EXCEPT AS OTHERWISE INDICATED FOR REQUIRED LABELS, DO NOT PERMANENTLY ATTACH OR IMPRINT MANUFACTURER'S OR PRODUCER'S NAMEPLATES OR TRADEMARKS ON EXPOSED SURFACES OF PRODUCTS WHICH WILL BE EXPOSED TO VIEW. 3. TRANSPORT PRODUCTS BY METHODS TO AVOID PRODUCT DAMAGE. DELIVER PRODUCTS IN UNDAMAGED CONDITION IN MANUFACTURER'S UNOPENED CONTAINERS. 4. PROVIDE EQUIPMENT AND PERSONNEL TO HANDLE PRODUCTS BY METHODS TO PREVENT DAMAGE. 5. PROMPTLY INSPECT SHIPMENTS TO ASSURE THAT PRODUCTS COMPLY WITH REQUIREMENTS, QUANTITIES ARE CORRECT, AND PRODUCTS ARE UNDAMAGED. 6. STORE PRODUCTS IN ACCORDANCE WITH MANUFACTURER'S INSTRUCTIONS, WITH SEALS AND LABELS INTACT AND LEGIBLE. STORE SENSITIVE PRODUCTS IN ENCLOSURES; MAINTAIN TEMPERATURE AND HUMIDITY RANGES RECOMMENDED BY MANUFACTURER.

1.	LOCATE REQUIRED LABELS AND STAMPS WHERE REQUIRED FOR OBSERVATION AFTER
	INSTALLATION ON AN ACCESSIBLE SURFACE WHICH, IN OCCUPIED SPACES, IS NOT
	CONSPICUOUS.
2.	EXCEPT AS OTHERWISE INDICATED FOR REQUIRED LABELS, DO NOT PERMANENTLY ATTACH
	OR IMPRINT MANUFACTURER'S OR PRODUCER'S NAMEPLATES OR TRADEMARKS ON
	EXPOSED SURFACES OF PRODUCTS WHICH WILL BE EXPOSED TO VIEW.
3.	TRANSPORT PRODUCTS BY METHODS TO AVOID PRODUCT DAMAGE. DELIVER PRODUCTS IN
	UNDAMAGED CONDITION IN MANUFACTURER'S UNOPENED CONTAINERS.
4.
	DAMAGE.
5.	PROMPTLY INSPECT SHIPMENTS TO ASSURE THAT PRODUCTS COMPLY WITH
	REQUIREMENTS, QUANTITIES ARE CORRECT, AND PRODUCTS ARE UNDAMAGED.
6.
	AND LABELS INTACT AND LEGIBLE. STORE SENSITIVE PRODUCTS IN ENCLOSURES; MAINTAIN
	TEMPERATURE AND HUMIDITY RANGES RECOMMENDED BY MANUFACTURER.

VARIATION. SUBMIT ALL SAMPLES OF INTERIOR FINISHES SIMULTANEOUSLY TO PERMIT COORDINAT
SELECTION OF COLORS AND FINISHES. TAG OR PERMANENTLY MARK EACH SAMPLE TO IDENTIFY TH

DRAWING NUMBER
WHERE SECTION IS LOCATED

DRAWING NUMBER
WHERE ELEVATION IS LOCATED

DRAWING NUMBER
WHERE ELEVATION IS LOCATED

SS Project Component
NNOO Project North
Key Plan CC

QUALITY CONTROL
1. MONITOR QUALITY CONTROL OVER SUPPLIERS, MANUFACTURERS, PRODUCTS, SERVICES, SITE CONDITIONS, AND WORKMANSHIP TO PRODUCE WORK OF SPECIFIED QUALITY. 2. INSTALLATION: EXCEPT AS MORE STRINGENT REQUIREMENTS ARE INDICATED ON THESE DRAWINGS AND IN THESE NOTES, COMPLY WITH GENERALLY ACCEPTED INDUSTRY STANDARDS AND INSTALL PRODUCTS IN STRICT COMPLIANCE WITH MANUFACTURER'S PRINTED INSTRUCTIONS. 3. WHEN EVALUATING APPEARANCE OR CONFORMANCE WITH DESIGN INTENT, THE WORDS "ACCEPTABLE," "VISIBLE," "INVISIBLE," "MATCHING," "ALIGNED," AND SIMILAR TERMS OF JUDGMENT SHALL MEAN "ACCEPTABLE, ETC., IN THE OPINION OF THE ARCHITECT OR OWNER." 4. SECURE PRODUCTS IN PLACE WITH POSITIVE ANCHORAGE DEVICES DESIGNED AND SIZED FOR THE APPLICATION. 5. PERFORM WORK BY PERSONS QUALIFIED TO PRODUCE WORKMANSHIP OR SPECIFIED QUALITY, FREE FROM DISTORTION OR DISFIGUREMENT.

QUALITY CONTROL

1. MONITOR QUALITY CONTROL OVER SUPPLIERS, MANUFACTURERS, PRODUCTS, SERVICES, SITE CONDITIONS, AND WORKMANSHIP TO PRODUCE WORK OF SPECIFIED QUALITY. 2. INSTALLATION: EXCEPT AS MORE STRINGENT REQUIREMENTS ARE INDICATED ON THESE DRAWINGS AND IN THESE NOTES, COMPLY WITH GENERALLY ACCEPTED INDUSTRY STANDARDS AND INSTALL PRODUCTS IN STRICT COMPLIANCE WITH MANUFACTURER'S PRINTED INSTRUCTIONS. 3. WHEN EVALUATING APPEARANCE OR CONFORMANCE WITH DESIGN INTENT, THE WORDS "ACCEPTABLE," "VISIBLE," "INVISIBLE," "MATCHING," "ALIGNED," AND SIMILAR TERMS OF JUDGMENT SHALL MEAN "ACCEPTABLE, ETC., IN THE OPINION OF THE ARCHITECT OR OWNER." 4. SECURE PRODUCTS IN PLACE WITH POSITIVE ANCHORAGE DEVICES DESIGNED AND SIZED FOR THE APPLICATION. 5. PERFORM WORK BY PERSONS QUALIFIED TO PRODUCE WORKMANSHIP OR SPECIFIED QUALITY, FREE FROM DISTORTION OR DISFIGUREMENT.

CONTRACT CLOSE-OUT
1. UPON COMPLETION OF PROJECT AND PRIOR TO FINAL PAYMENT, SUBMIT OPERATION AND MAINTENANCE INSTRUCTIONS, ARRANGED BY SYSTEM. AS A MINIMUM PROVIDE DATA FOR: MECHANICAL EQUIPMENT AND CONTROLS, AND ELECTRICAL EQUIPMENT AND CONTROLS. 2. PROVIDE INFORMATION TO OWNER BOUND IN A THREE-RING BINDER. ASSEMBLE DOCUMENTS EXECUTED BY SUBCONTRACTORS, SUPPLIERS, AND MANUFACTURERS WITH A TABLE OF CONTENTS. BINDERS SHALL INCLUDE OPERATION AND MAINTENANCE INSTRUCTIONS, ARRANGED BY SYSTEM. FOR EACH SYSTEM GIVE NAMES, ADDRESSES, AND TELEPHONE NUMBERS OF SUBCONTRACTORS AND SUPPLIERS. PROVIDE THE FOLLOWING INFORMATION: A LIST OF PARTS AND EQUIPMENT, OPERATION AND MAINTENANCE INSTRUCTIONS, SHOP DRAWINGS AND PRODUCT DATA, WARRANTIES, AS-BUILT DRAWINGS / MARK-UPS OF FINAL CONSTRUCTION. 3. PROVIDE OWNER WITH A WRITTEN WARRANTY COVERING ENTIRE PROJECT FOR 1 YEAR. IN ADDITION, WHERE SEPARATE WARRANTEES, FOR CERTAIN PORTIONS OF WORK, ARE FOR LONGER PERIODS, CONTRACTOR'S WARRANTY SHALL BE EXTENDED TO COVER SUCH LONGER PERIODS. 4. SCHEDULE A FINAL CLEANING OF PROJECT AT A TIME IMMEDIATELY PRIOR TO ACCEPTANCE OF COMPLETED PROJECT BY OWNER. CLEAN SURFACES EXPOSED TO VIEW; REMOVE TEMPORARY LABELS, STAINS AND FOREIGN SUBSTANCES, POLISH TRANSPARENT AND GLOSSY SURFACES. CLEAN EQUIPMENT AND FIXTURES TO A SANITARY CONDITIONS, CLEAN OR REPLACE FILTERS OF MECHANICAL EQUIPMENT. 5. UPON NOTIFICATION OF COMPLETION OF THE WORK AND DELIVERY OF THE CONTRACTOR'S PUNCHLIST, THE ARCHITECT SHALL PREPARE A PUNCHLIST OF CORRECTIONS, UNSATISFACTORY AND/OR INCOMPLETE WORK. FINAL PAYMENT WILL BE CONTINGENT UPON COMPLETION OF THESE ITEMS UNDER THE TERMS AND CONDITIONS OF THE OWNER/CONTRACTOR AGREEMENT. 6. PRIOR TO REQUEST FOR FINAL REQUEST FOR PAYMENT, CONTRACTOR SHALL COMPLETE THE FOLLOWING ITEMS AND PLACE THEM ON FILE WITH OWNER: * RELEASE OF LIENS FROM SUBCONTRACTORS SIGNED BY EACH. * WRITTEN OR PRINTED OPERATING INSTRUCTIONS AND/OR MANUALS. * DEMONSTRATION AND EXPLANATION OF MECHANICAL AND ELECTRICAL SYSTEMS TO OWNER. * ELECTRICAL PANELS PROPERLY LABELED (TYPEWRITTEN), VALVES, PIPES, DUCTS, ETC. PROPERLY MARKED AND COLOR CODED. * SYSTEMS COMPLETELY IN OPERATION WITH BALANCING COMPLETED. * COMPLETION OF PUNCHLIST CORRECTIONS, OR PROVIDED A VALUE OF UNCOMPLETED ITEMS. * FINAL REQUISITION TO LIST ALL PREVIOUS AND ADDITIONAL CHANGE ORDERS, REQUEST OF EXTRAS, PREVIOUS REQUESTS FOR EXTENSION OF TIME, ETC. * CERTIFICATION OF FINAL INSPECTION FROM MUNICIPAL AGENCIES AS REQUIRED. * PROVIDE COMPLETE SET OF AS-BUILT DRAWINGS TO OWNER.

CONTRACT CLOSE-OUT

1. UPON COMPLETION OF PROJECT AND PRIOR TO FINAL PAYMENT, SUBMIT OPERATION AND MAINTENANCE INSTRUCTIONS, ARRANGED BY SYSTEM. AS A MINIMUM PROVIDE DATA FOR: MECHANICAL EQUIPMENT AND CONTROLS, AND ELECTRICAL EQUIPMENT AND CONTROLS. 2. PROVIDE INFORMATION TO OWNER BOUND IN A THREE-RING BINDER. ASSEMBLE DOCUMENTS EXECUTED BY SUBCONTRACTORS, SUPPLIERS, AND MANUFACTURERS WITH A TABLE OF CONTENTS. BINDERS SHALL INCLUDE OPERATION AND MAINTENANCE INSTRUCTIONS, ARRANGED BY SYSTEM. FOR EACH SYSTEM GIVE NAMES, ADDRESSES, AND TELEPHONE NUMBERS OF SUBCONTRACTORS AND SUPPLIERS. PROVIDE THE FOLLOWING INFORMATION: A LIST OF PARTS AND EQUIPMENT, OPERATION AND MAINTENANCE INSTRUCTIONS, SHOP DRAWINGS AND PRODUCT DATA, WARRANTIES, AS-BUILT DRAWINGS / MARK-UPS OF FINAL CONSTRUCTION. 3. PROVIDE OWNER WITH A WRITTEN WARRANTY COVERING ENTIRE PROJECT FOR 1 YEAR. IN ADDITION, WHERE SEPARATE WARRANTEES, FOR CERTAIN PORTIONS OF WORK, ARE FOR LONGER PERIODS, CONTRACTOR'S WARRANTY SHALL BE EXTENDED TO COVER SUCH LONGER PERIODS. 4. SCHEDULE A FINAL CLEANING OF PROJECT AT A TIME IMMEDIATELY PRIOR TO ACCEPTANCE OF COMPLETED PROJECT BY OWNER. CLEAN SURFACES EXPOSED TO VIEW; REMOVE TEMPORARY LABELS, STAINS AND FOREIGN SUBSTANCES, POLISH TRANSPARENT AND GLOSSY SURFACES. CLEAN EQUIPMENT AND FIXTURES TO A SANITARY CONDITIONS, CLEAN OR REPLACE FILTERS OF MECHANICAL EQUIPMENT. 5. UPON NOTIFICATION OF COMPLETION OF THE WORK AND DELIVERY OF THE CONTRACTOR'S PUNCHLIST, THE ARCHITECT SHALL PREPARE A PUNCHLIST OF CORRECTIONS, UNSATISFACTORY AND/OR INCOMPLETE WORK. FINAL PAYMENT WILL BE CONTINGENT UPON COMPLETION OF THESE ITEMS UNDER THE TERMS AND CONDITIONS OF THE OWNER/CONTRACTOR AGREEMENT. 6. PRIOR TO REQUEST FOR FINAL REQUEST FOR PAYMENT, CONTRACTOR SHALL COMPLETE THE FOLLOWING ITEMS AND PLACE THEM ON FILE WITH OWNER: * RELEASE OF LIENS FROM SUBCONTRACTORS SIGNED BY EACH. * WRITTEN OR PRINTED OPERATING INSTRUCTIONS AND/OR MANUALS. * DEMONSTRATION AND EXPLANATION OF MECHANICAL AND ELECTRICAL SYSTEMS TO OWNER. * ELECTRICAL PANELS PROPERLY LABELED (TYPEWRITTEN), VALVES, PIPES, DUCTS, ETC. PROPERLY MARKED AND COLOR CODED. * SYSTEMS COMPLETELY IN OPERATION WITH BALANCING COMPLETED. * COMPLETION OF PUNCHLIST CORRECTIONS, OR PROVIDED A VALUE OF UNCOMPLETED ITEMS. * FINAL REQUISITION TO LIST ALL PREVIOUS AND ADDITIONAL CHANGE ORDERS, REQUEST OF EXTRAS, PREVIOUS REQUESTS FOR EXTENSION OF TIME, ETC. * CERTIFICATION OF FINAL INSPECTION FROM MUNICIPAL AGENCIES AS REQUIRED. * PROVIDE COMPLETE SET OF AS-BUILT DRAWINGS TO OWNER.

1.
	SITE CONDITIONS, AND WORKMANSHIP TO PRODUCE WORK OF SPECIFIED QUALITY.
2.	INSTALLATION: EXCEPT AS MORE STRINGENT REQUIREMENTS ARE INDICATED ON THESE
	DRAWINGS AND IN THESE NOTES, COMPLY WITH GENERALLY ACCEPTED INDUSTRY
	STANDARDS AND INSTALL PRODUCTS IN STRICT COMPLIANCE WITH MANUFACTURER'S
	PRINTED INSTRUCTIONS.
3.
	"ACCEPTABLE," "VISIBLE," "INVISIBLE," "MATCHING," "ALIGNED," AND SIMILAR TERMS OF
	JUDGMENT SHALL MEAN "ACCEPTABLE, ETC., IN THE OPINION OF THE ARCHITECT OR
	OWNER."
4.
	FOR THE APPLICATION.
5.	PERFORM WORK BY PERSONS QUALIFIED TO PRODUCE WORKMANSHIP OR SPECIFIED
	QUALITY, FREE FROM DISTORTION OR DISFIGUREMENT.

1.	UPON COMPLETION OF PROJECT AND PRIOR TO FINAL PAYMENT, SUBMIT OPERATION AND

2.
	EXECUTED BY SUBCONTRACTORS, SUPPLIERS, AND MANUFACTURERS WITH A TABLE OF CONTENTS.
	BINDERS SHALL INCLUDE OPERATION AND MAINTENANCE INSTRUCTIONS, ARRANGED BY SYSTEM. FO
	EACH SYSTEM GIVE NAMES, ADDRESSES, AND TELEPHONE NUMBERS OF SUBCONTRACTORS AND
	SUPPLIERS. PROVIDE THE FOLLOWING INFORMATION: A LIST OF PARTS AND EQUIPMENT, OPERATION
	AND MAINTENANCE INSTRUCTIONS, SHOP DRAWINGS AND PRODUCT DATA, WARRANTIES, AS-BUILT
	DRAWINGS / MARK-UPS OF FINAL CONSTRUCTION.
3.	PROVIDE OWNER WITH A WRITTEN WARRANTY COVERING ENTIRE PROJECT FOR 1 YEAR. IN ADDITION
	CONTRACTOR'S WARRANTY SHALL BE EXTENDED TO COVER SUCH LONGER PERIODS.
4.
	LABELS, STAINS AND FOREIGN SUBSTANCES, POLISH TRANSPARENT AND GLOSSY SURFACES. CLEAN
	EQUIPMENT AND FIXTURES TO A SANITARY CONDITIONS, CLEAN OR REPLACE FILTERS OF MECHANIC
	EQUIPMENT.
5.	UPON NOTIFICATION OF COMPLETION OF THE WORK AND DELIVERY OF THE CONTRACTOR'S
	ITEMS UNDER THE TERMS AND CONDITIONS OF THE OWNER/CONTRACTOR AGREEMENT.
6.
	FOLLOWING ITEMS AND PLACE THEM ON FILE WITH OWNER:
	*	RELEASE OF LIENS FROM SUBCONTRACTORS SIGNED BY EACH.
	*	WRITTEN OR PRINTED OPERATING INSTRUCTIONS AND/OR MANUALS.
	*
	*	ELECTRICAL PANELS PROPERLY LABELED (TYPEWRITTEN), VALVES, PIPES, DUCTS, ETC. PROPERL
		MARKED AND COLOR CODED.
	*	SYSTEMS COMPLETELY IN OPERATION WITH BALANCING COMPLETED.
	*
	*	FINAL REQUISITION TO LIST ALL PREVIOUS AND ADDITIONAL CHANGE ORDERS, REQUEST OF EXTR
		PREVIOUS REQUESTS FOR EXTENSION OF TIME, ETC.
	*	CERTIFICATION OF FINAL INSPECTION FROM MUNICIPAL AGENCIES AS REQUIRED.
	*	PROVIDE COMPLETE SET OF AS-BUILT DRAWINGS TO OWNER.

Seal(s) TTOONN
-- 150 W. Jefferson Avenue., Suite 1300 Detroit, MI, US 48226 YYRR NORR.COM

CHANGE ORDER PROCEDURES
1. THE ARCHITECT MAY ISSUE MINOR CHANGES IN WORK, NOT INVOLVING AN ADJUSTMENT TO CONTRACT SUM OR CONTRACT TIME, BY ISSUING CLARIFICATIONS. THE ARCHITECT MAY ISSUE CHANGES IN WORK INVOLVING AN ADJUSTMENT TO CONTRACT SUM OR CONTRACT TIME BY ISSUING BULLETINS. 2. ARCHITECT MAY ISSUE A BULLETIN WHICH INCLUDES A DETAILED DESCRIPTION OF A PROPOSED CHANGE WITH SUPPLEMENTARY OR REVISED DRAWINGS. CONTRACTOR SHALL PREPARE AND SUBMIT AN ESTIMATE WITHIN ONE (1) WEEK, INCLUDING A PROPOSED CHANGE IN CONTRACT TIME FOR EXECUTING CHANGE AND PERIOD OF TIME DURING WHICH REQUESTED PRICE WILL BE CONSIDERED VALID. 3. CONTRACTOR MAY PROPOSE A CHANGE BY SUBMITTING A REQUEST FOR CHANGE TO PROJECT MANAGER, DESCRIBING PROPOSED CHANGE AND FULL EFFECT ON WORK, WITH A STATEMENT DESCRIBING REASON FOR CHANGE, AND EFFECT ON CONTRACT SUM AND CONTRACT TIME WITH FULL DOCUMENTATION. 4. MAINTAIN DETAILED RECORDS OF WORK DONE ON A TIME AND MATERIAL BASIS. PROVIDE FULL INFORMATION REQUIRED FOR EVALUATION OF PROPOSED CHANGES, AND TO SUBSTANTIATE COSTS OF CHANGES IN WORK. 5. ALL CHANGE ORDERS ARE TO BE APPROVED IN WRITING BY OWNER. 6. DOCUMENT EACH QUOTATION FOR A CHANGE IN COST OR TIME WITH SUFFICIENT DATA TO ALLOW EVALUATION OF QUOTATION. PROVIDE DATA TO SUPPORT COMPUTATIONS, INCLUDING: * ORIGIN AND DATE OF CLAIM WITH DATES AND TIMES WORK WAS PERFORMED, BY WHOM AND TIME RECORDS AND WAGES RATES PAID. * QUANTITIES OF PRODUCTS, LABOR, AND EQUIPMENT. * INVOICES AND RECEIPTS FOR PRODUCTS, EQUIPMENT, AND CONTRACTS, SIMILARLY DOCUMENTED. * TAXES AND INSURANCE. * OVERHEAD AND PROFIT. * JUSTIFICATION FOR CHANGE IN CONTRACT TIME. * CREDIT FOR DELETIONS FROM CONTRACT, SIMILARLY DOCUMENTED.

CHANGE ORDER PROCEDURES

1. THE ARCHITECT MAY ISSUE MINOR CHANGES IN WORK, NOT INVOLVING AN ADJUSTMENT TO CONTRACT SUM OR CONTRACT TIME, BY ISSUING CLARIFICATIONS. THE ARCHITECT MAY ISSUE CHANGES IN WORK INVOLVING AN ADJUSTMENT TO CONTRACT SUM OR CONTRACT TIME BY ISSUING BULLETINS. 2. ARCHITECT MAY ISSUE A BULLETIN WHICH INCLUDES A DETAILED DESCRIPTION OF A PROPOSED CHANGE WITH SUPPLEMENTARY OR REVISED DRAWINGS. CONTRACTOR SHALL PREPARE AND SUBMIT AN ESTIMATE WITHIN ONE (1) WEEK, INCLUDING A PROPOSED CHANGE IN CONTRACT TIME FOR EXECUTING CHANGE AND PERIOD OF TIME DURING WHICH REQUESTED PRICE WILL BE CONSIDERED VALID. 3. CONTRACTOR MAY PROPOSE A CHANGE BY SUBMITTING A REQUEST FOR CHANGE TO PROJECT MANAGER, DESCRIBING PROPOSED CHANGE AND FULL EFFECT ON WORK, WITH A STATEMENT DESCRIBING REASON FOR CHANGE, AND EFFECT ON CONTRACT SUM AND CONTRACT TIME WITH FULL DOCUMENTATION. 4. MAINTAIN DETAILED RECORDS OF WORK DONE ON A TIME AND MATERIAL BASIS. PROVIDE FULL INFORMATION REQUIRED FOR EVALUATION OF PROPOSED CHANGES, AND TO SUBSTANTIATE COSTS OF CHANGES IN WORK. 5. ALL CHANGE ORDERS ARE TO BE APPROVED IN WRITING BY OWNER. 6. DOCUMENT EACH QUOTATION FOR A CHANGE IN COST OR TIME WITH SUFFICIENT DATA TO ALLOW EVALUATION OF QUOTATION. PROVIDE DATA TO SUPPORT COMPUTATIONS, INCLUDING: * ORIGIN AND DATE OF CLAIM WITH DATES AND TIMES WORK WAS PERFORMED, BY WHOM AND TIME RECORDS AND WAGES RATES PAID. * QUANTITIES OF PRODUCTS, LABOR, AND EQUIPMENT. * INVOICES AND RECEIPTS FOR PRODUCTS, EQUIPMENT, AND CONTRACTS, SIMILARLY DOCUMENTED. * TAXES AND INSURANCE. * OVERHEAD AND PROFIT. * JUSTIFICATION FOR CHANGE IN CONTRACT TIME. * CREDIT FOR DELETIONS FROM CONTRACT, SIMILARLY DOCUMENTED.

COORDINATION
1. COORDINATE SCHEDULING, SUBMITTALS, AND WORK OF VARIOUS TRADES TO ASSURE AN EFFICIENT AND ORDERLY SEQUENCE OF INSTALLATION OF INTERDEPENDENT ELEMENTS. 2. VERIFY THAT UTILITY REQUIREMENT CHARACTERISTICS OF OPERATING EQUIPMENT ARE COMPATIBLE WITH BUILDING UTILITIES. COORDINATE WORK OF VARIOUS SECTIONS OF SPECIFICATIONS HAVING INTERDEPENDENT RESPONSIBILITIES FOR INSTALLING, CONNECTING TO, AND PLACING IN SERVICE, SUCH EQUIPMENT. 3. IN FINISHED AREAS, EXCEPT AS OTHERWISE INDICATED, CONCEAL PIPES, DUCTS, AND WIRING WITHIN CONSTRUCTION. COORDINATE LOCATIONS OF FIXTURES AND OUTLETS WITH FINISH ELEMENTS. 4. COORDINATE MECHANICAL AND ELECTRICAL PORTIONS OF WORK WITH OTHER PORTIONS OF WORK. COORDINATE PROGRESS SCHEDULES, INCLUDING DATES FOR SUBMITTALS AND FOR DELIVERY. 5. CONDUCT CONFERENCES AMONG SUBCONTRACTORS, SEPARATE CONTRACTORS, AND OTHERS CONCERNED WITH WORK, TO ESTABLISH AND MAINTAIN COORDINATION AND SCHEDULES, AND TO RESOLVE COORDINATION MATTERS IN DISPUTE. 6. COORDINATE SPACE REQUIREMENTS AND INSTALLATION OF MECHANICAL AND ELECTRICAL WORK WHICH ARE INDICATED BY DIAGRAM ON DRAWINGS. FOLLOW ROUTING SHOWN FOR PIPES, DUCTS, AND CONDUIT, AS CLOSELY AS PRACTICABLE; PLACE RUNS PARALLEL WITH LINES OF BUILDING. UTILIZE SPACES EFFICIENTLY TO MAXIMIZE ACCESSIBILITY FOR OTHER INSTALLATIONS, FOR MAINTENANCE, AND FOR REPAIRS. 7. EXECUTE CUTTING, FITTING, AND PATCHING BY METHODS WHICH WILL AVOID DAMAGE TO OTHER WORK, AND PROVIDE PROPER SURFACES TO RECEIVE PATCHING AND FINISHING. REFINISH SURFACES TO MATCH ADJACENT FINISHES. FOR CONTINUOUS SURFACES, REFINISH TO NEAREST INTERSECTION, FOR AN ASSEMBLY, REFINISH ENTIRE UNIT. RESTORE WORK WITH NEW PRODUCTS IN ACCORDANCE WITH REQUIREMENTS OF CONTRACT DOCUMENTS. 8. FIT WORK TIGHT TO PIPES, SLEEVES, DUCTS, CONDUIT, AND OTHER PENETRATIONS THROUGH SURFACES. MAINTAIN INTEGRITY OF WALL, CEILING, OR FLOOR CONSTRUCTION; COMPLETELY SEAL VOIDS. 9. CHASING OR CUTTING OF EXISTING CORE AND OTHER FIRE-RATED WALLS FOR INSTALLATION OF NEW CONSTRUCTION SHALL NOT BE PERMITTED. 10.COORDINATE USE OF PREMISES UNDER DIRECTION OF BUILDING MANAGER. OBTAIN A COPY OF OWNER OR LANDLORD'S RULES AND REGULATIONS GOVERNING CONSTRUCTION ON PREMISES. 11.IDENTIFY HAZARDOUS SUBSTRATES OR CONDITIONS EXPOSED DURING WORK TO OWNER FOR REMEDY. 12.FOR PRODUCTS SPECIFIED BY ASSOCIATION OR TRADE STANDARDS, COMPLY WITH REQUIREMENTS OF STANDARD, EXCEPT WHEN MORE RIGID REQUIREMENTS ARE SPECIFIED OR ARE REQUIRED BY APPLICABLE CODES. DATE OF STANDARD IS THAT IN EFFECT AS OF DATE OF OWNER-CONTRACTOR AGREEMENT, EXCEPT WHEN A SPECIFIC DATE IS SPECIFIED.

COORDINATION

1. COORDINATE SCHEDULING, SUBMITTALS, AND WORK OF VARIOUS TRADES TO ASSURE AN EFFICIENT AND ORDERLY SEQUENCE OF INSTALLATION OF INTERDEPENDENT ELEMENTS. 2. VERIFY THAT UTILITY REQUIREMENT CHARACTERISTICS OF OPERATING EQUIPMENT ARE COMPATIBLE WITH BUILDING UTILITIES. COORDINATE WORK OF VARIOUS SECTIONS OF SPECIFICATIONS HAVING INTERDEPENDENT RESPONSIBILITIES FOR INSTALLING, CONNECTING TO, AND PLACING IN SERVICE, SUCH EQUIPMENT. 3. IN FINISHED AREAS, EXCEPT AS OTHERWISE INDICATED, CONCEAL PIPES, DUCTS, AND WIRING WITHIN CONSTRUCTION. COORDINATE LOCATIONS OF FIXTURES AND OUTLETS WITH FINISH ELEMENTS. 4. COORDINATE MECHANICAL AND ELECTRICAL PORTIONS OF WORK WITH OTHER PORTIONS OF WORK. COORDINATE PROGRESS SCHEDULES, INCLUDING DATES FOR SUBMITTALS AND FOR DELIVERY. 5. CONDUCT CONFERENCES AMONG SUBCONTRACTORS, SEPARATE CONTRACTORS, AND OTHERS CONCERNED WITH WORK, TO ESTABLISH AND MAINTAIN COORDINATION AND SCHEDULES, AND TO RESOLVE COORDINATION MATTERS IN DISPUTE. 6. COORDINATE SPACE REQUIREMENTS AND INSTALLATION OF MECHANICAL AND ELECTRICAL WORK WHICH ARE INDICATED BY DIAGRAM ON DRAWINGS. FOLLOW ROUTING SHOWN FOR PIPES, DUCTS, AND CONDUIT, AS CLOSELY AS PRACTICABLE; PLACE RUNS PARALLEL WITH LINES OF BUILDING. UTILIZE SPACES EFFICIENTLY TO MAXIMIZE ACCESSIBILITY FOR OTHER INSTALLATIONS, FOR MAINTENANCE, AND FOR REPAIRS. 7. EXECUTE CUTTING, FITTING, AND PATCHING BY METHODS WHICH WILL AVOID DAMAGE TO OTHER WORK, AND PROVIDE PROPER SURFACES TO RECEIVE PATCHING AND FINISHING. REFINISH SURFACES TO MATCH ADJACENT FINISHES. FOR CONTINUOUS SURFACES, REFINISH TO NEAREST INTERSECTION, FOR AN ASSEMBLY, REFINISH ENTIRE UNIT. RESTORE WORK WITH NEW PRODUCTS IN ACCORDANCE WITH REQUIREMENTS OF CONTRACT DOCUMENTS. 8. FIT WORK TIGHT TO PIPES, SLEEVES, DUCTS, CONDUIT, AND OTHER PENETRATIONS THROUGH SURFACES. MAINTAIN INTEGRITY OF WALL, CEILING, OR FLOOR CONSTRUCTION; COMPLETELY SEAL VOIDS. 9. CHASING OR CUTTING OF EXISTING CORE AND OTHER FIRE-RATED WALLS FOR INSTALLATION OF NEW CONSTRUCTION SHALL NOT BE PERMITTED. 10.COORDINATE USE OF PREMISES UNDER DIRECTION OF BUILDING MANAGER. OBTAIN A COPY OF OWNER OR LANDLORD'S RULES AND REGULATIONS GOVERNING CONSTRUCTION ON PREMISES. 11.IDENTIFY HAZARDOUS SUBSTRATES OR CONDITIONS EXPOSED DURING WORK TO OWNER FOR REMEDY. 12.FOR PRODUCTS SPECIFIED BY ASSOCIATION OR TRADE STANDARDS, COMPLY WITH REQUIREMENTS OF STANDARD, EXCEPT WHEN MORE RIGID REQUIREMENTS ARE SPECIFIED OR ARE REQUIRED BY APPLICABLE CODES. DATE OF STANDARD IS THAT IN EFFECT AS OF DATE OF OWNER-CONTRACTOR AGREEMENT, EXCEPT WHEN A SPECIFIC DATE IS SPECIFIED.

1.	THE ARCHITECT MAY ISSUE MINOR CHANGES IN WORK, NOT INVOLVING AN ADJUSTMENT TO CONTRA
	SUM OR CONTRACT TIME, BY ISSUING CLARIFICATIONS. THE ARCHITECT MAY ISSUE CHANGES IN WO
	INVOLVING AN ADJUSTMENT TO CONTRACT SUM OR CONTRACT TIME BY ISSUING BULLETINS.
2.
	CHANGE WITH SUPPLEMENTARY OR REVISED DRAWINGS. CONTRACTOR SHALL PREPARE AND SUBMI
	AN ESTIMATE WITHIN ONE (1) WEEK, INCLUDING A PROPOSED CHANGE IN CONTRACT TIME FOR
	EXECUTING CHANGE AND PERIOD OF TIME DURING WHICH REQUESTED PRICE WILL BE CONSIDERED
	VALID.
3.
	DESCRIBING REASON FOR CHANGE, AND EFFECT ON CONTRACT SUM AND CONTRACT TIME WITH FUL
	DOCUMENTATION.
4.
	INFORMATION REQUIRED FOR EVALUATION OF PROPOSED CHANGES, AND TO SUBSTANTIATE COSTS
	OF CHANGES IN WORK.
5.	ALL CHANGE ORDERS ARE TO BE APPROVED IN WRITING BY OWNER.
6.
	EVALUATION OF QUOTATION. PROVIDE DATA TO SUPPORT COMPUTATIONS, INCLUDING:
	*	ORIGIN AND DATE OF CLAIM WITH DATES AND TIMES WORK WAS PERFORMED, BY WHOM AND TIME
		RECORDS AND WAGES RATES PAID.
	*	QUANTITIES OF PRODUCTS, LABOR, AND EQUIPMENT.
	*	INVOICES AND RECEIPTS FOR PRODUCTS, EQUIPMENT, AND CONTRACTS, SIMILARLY DOCUMENTE
	*	TAXES AND INSURANCE.
	*	OVERHEAD AND PROFIT.
	*	JUSTIFICATION FOR CHANGE IN CONTRACT TIME.
	*	CREDIT FOR DELETIONS FROM CONTRACT, SIMILARLY DOCUMENTED.

1.	COORDINATE SCHEDULING, SUBMITTALS, AND WORK OF VARIOUS TRADES TO ASSURE AN EFFICIENT
	AND ORDERLY SEQUENCE OF INSTALLATION OF INTERDEPENDENT ELEMENTS.
2.	VERIFY THAT UTILITY REQUIREMENT CHARACTERISTICS OF OPERATING EQUIPMENT ARE COMPATIBL
	WITH BUILDING UTILITIES. COORDINATE WORK OF VARIOUS SECTIONS OF SPECIFICATIONS HAVING
	INTERDEPENDENT RESPONSIBILITIES FOR INSTALLING, CONNECTING TO, AND PLACING IN SERVICE,
	SUCH EQUIPMENT.
3.	IN FINISHED AREAS, EXCEPT AS OTHERWISE INDICATED, CONCEAL PIPES, DUCTS, AND WIRING WITHI
	CONSTRUCTION. COORDINATE LOCATIONS OF FIXTURES AND OUTLETS WITH FINISH ELEMENTS.
4.	COORDINATE MECHANICAL AND ELECTRICAL PORTIONS OF WORK WITH OTHER PORTIONS OF WORK
5.
	RESOLVE COORDINATION MATTERS IN DISPUTE.
6.
	WHICH ARE INDICATED BY DIAGRAM ON DRAWINGS. FOLLOW ROUTING SHOWN FOR PIPES, DUCTS, A
	CONDUIT, AS CLOSELY AS PRACTICABLE; PLACE RUNS PARALLEL WITH LINES OF BUILDING. UTILIZE
	SPACES EFFICIENTLY TO MAXIMIZE ACCESSIBILITY FOR OTHER INSTALLATIONS, FOR MAINTENANCE,
	AND FOR REPAIRS.
7.
	WORK, AND PROVIDE PROPER SURFACES TO RECEIVE PATCHING AND FINISHING. REFINISH SURFAC
	TO MATCH ADJACENT FINISHES. FOR CONTINUOUS SURFACES, REFINISH TO NEAREST INTERSECTIO
	FOR AN ASSEMBLY, REFINISH ENTIRE UNIT. RESTORE WORK WITH NEW PRODUCTS IN ACCORDANCE
	WITH REQUIREMENTS OF CONTRACT DOCUMENTS.
8.
	SURFACES. MAINTAIN INTEGRITY OF WALL, CEILING, OR FLOOR CONSTRUCTION; COMPLETELY SEAL
	VOIDS.
9.	CHASING OR CUTTING OF EXISTING CORE AND OTHER FIRE-RATED WALLS FOR INSTALLATION OF NE
	CONSTRUCTION SHALL NOT BE PERMITTED.
10.
11.
	REMEDY.
12.	FOR PRODUCTS SPECIFIED BY ASSOCIATION OR TRADE STANDARDS, COMPLY WITH REQUIREMENTS
	OF STANDARD, EXCEPT WHEN MORE RIGID REQUIREMENTS ARE SPECIFIED OR ARE REQUIRED BY
	APPLICABLE CODES. DATE OF STANDARD IS THAT IN EFFECT AS OF DATE OF OWNER-CONTRACTOR
	AGREEMENT, EXCEPT WHEN A SPECIFIC DATE IS SPECIFIED.

Project Manager KJ	Drawn NC
Project Leader NC	AA Checked KJ
Client NNII WAYNE STATE UNIVERSITY CLIENT ADDRESS
MMII Project WSU UNIVERSITY AUDITORIUM RENOVATION 5203 CASS AVE., DETROIT, MI 48202
Drawing Title LLEE GENERAL NOTES, ABBREVIATIONS, & SYMBOL LEGEND
RR Scale 12" = 1'-0"
Project No. ED2026-0133
PP Drawing No. A01-01

EXTERIOR WALL/ CURTAIN WALL/
PARTITION ASSEMBLY TAG

This is the opportunity summary page. It provides an overview of this opportunity and a preview of the attached documentation.

Daily notification on new contract opportunities

With GovernmentContracts, you can:

Find more opportunities and win more business
Receive daily alerts for all new bid opportunities
Get contract opportunities matched to your business

ONE WEEK FREE TRIAL

WSU Project Numbers

Attachment Preview

See also