RFP - Professional Construction Management Services for Rundel Memorial Library

Agency:	City of Rochester
State:	New York
Type of Government:	State & Local
Category:	R - Professional, Administrative and Management Support Services
Posted:	Nov 3, 2023
Due:	Nov 28, 2023
Publication URL:	To access bid details, please log in.

RFP - Professional Construction Management Services for Rundel Memorial Library Exterior Envelope Repairs Project No. 19010

The City is seeking the services of a Consultant to perform the following services to implement the Project. Respondent’s proposal shall address each of the following services and identified tasks. The proposal shall address each of the requested services, using the same identifying language, including any paragraph or section numbers or letters as used in the RFP.

Services will involve providing a qualified Construction Manager / Project Representative & Construction Inspection staff for the duration of the project. Including but not limited to: providing a full time Project Representative, construction inspection and support staff as needed. Experience in historic restoration / masonry building renovations along with familiarity in mechanical & electrical systems is desired.

The personnel would work under the supervision of a City project manager and perform technical duties associated with the project. These duties would include but are not limited to observation of the work, quality assurance & control, submission of daily construction reports & photographs; review of contractor invoices & change orders; and coordination between the design engineer(s), contractor, agencies having jurisdiction, utility companies, the general public and the City project manager. All other duties are as described in the Draft Professional Service Agreement for Professional Services included with this RFP.

This Project consists of exterior envelope repairs to the historic Rundel Memorial Library located at 115 South Avenue, Rochester, NY 14604.

The scope of the project consists of but is not limited to, exterior rehabilitation and repair to the exterior masonry envelope materials, including brick, cast stone, precast concrete, and limestone, abatement of identified asbestos‐ and lead‐containing materials, masonry repairs and replacement, roofing replacement, and window repairs. Alternates include limited interior masonry repairs, penthouse roofing replacement, catwalk replacement, and other Work indicated in the Contract Documents.

The Project Representative and their staff will need to coordinate and oversee (QA / QC) the work (including work by others) so that it conforms to the drawings and specifications accordingly.

Drawings and specifications are available at https://www.bidnetdirect.com/new‐york/city‐of-rochester/ after 11/06/23 for review.

View the RFP

RFP Schedule and Delivery Information
Proposals must be received digitally by the City no later than 12:00 PM Tuesday, 11/28/2023.
Proposals shall be submitted in PDF version to:
Andrew Wojewodzic, Manager of Construction
andrew.wojewodzic@cityofrochester.gov : (585) 428-6523

Attachment Preview

Request for Proposals

RUNDEL MEMORIAL LIBRARY

EXTERIOR BUILDING ENVELOPE REPAIRS

PROJECT #19010 / BUILDING #7.11

CONSTRUCTION MANAGEMENT & RESIDENT PROJECT

REPRESENTATIVE / INSPECTION SERVICES

Department of Environmental Services

Bureau of Architecture and Engineering

Holly E. Barrett, P.E. / City Engineer

Issued: November 2, 2023

Proposals to be received by 12:00 PM

On Tuesday, November 28, 2023

Submit Electronic Proposals in PDF to:

Andy Wojewodzic, Manager of Construction

andrew.wojewodzic@cityofrochester.gov

1 of 64

REQUEST FOR PROPOSAL

The City of Rochester is seeking proposals from qualified Consultants (“Consultant(s)”) to provide Construction

Management and Resident Project Representation (RPR) services for the Rundel Memorial Library Exterior Envelope

Repairs Project (the “Project”) as described herein. The project is located at 115 South Avenue, Rochester, NY 14604.

Project Description

This Project is partially funded through the American Rescue Plan Act of 2021 (ARPA) and contains some federal

funding requirements.

The scope of the project consists of but is not limited to, exterior rehabilitation and repair to the exterior masonry

envelope materials, including brick, cast stone, precast concrete, and limestone, abatement of identified asbestos‐ and

lead‐containing materials, masonry repairs and replacement, roofing replacement, and window repairs. Alternates

include limited interior masonry repairs, penthouse roofing replacement, catwalk replacement, and other Work

indicated in the Contract Documents. The project was designed by Bero Architecture, PLLC.

This Project includes City M/WBE and Workforce Goals. Plans for both M/WBE Utilization and Workforce Staffing must

be submitted by all Consultants who propose to perform the work in this RFP and approved by the City’s M/WBE Officer

prior to an agreement being executed.

Bid specifications & drawings are available for review online via https://www.bidnetdirect.com/new‐york/city‐of‐

rochester/ on or after November 6, 2023. The Engineers estimate and other funding information is available by

contacting andrew.wojewodzic@cityofrochester.gov.

Construction duration is 627 calendar days anticipated from spring 2024 with substantial completion in late 2025.

Timeline

Activity

Time

Date

RFP Release

11/02/2023

Pre‐Bid Meeting

10:00 AM

11/14/2023

Deadline for questions

12:00 (NOON)

11/17/2023

Response for questions submitted

11/22/2023

Proposals due

12:00 PM

11/28/2023

Consultant Selection and Award

Notification

City Council Approval of agreement

with Consultant

January 2024

February

2024

Agreement Start Date

March 2024

The dates shown above may be subject to change within the City of Rochester’s sole discretion and upon written notification as set forth herein.

2 of 64

Communications

All communications by parties who have indicated an intent to submit or have submitted a proposal in response to this RFP

(“Respondents”), including any questions or requests for clarifications, submission of the proposal, requests for status

updates about the proposal selection process and any other inquiries whatsoever concerning this RFP shall be sent, in

writing, to the following City staff person (“City Contact”):

Andrew Wojewodzic, Manager of Construction

andrew.wojewodzic@cityofrochester.gov (585) 428‐6523

No contact is permitted with any other City staff member with regard to this RFP during the RFP process unless

specifically authorized in writing. Prohibited contact may be grounds for disqualification.

To ensure that all Respondents have a clear understanding of the scope and requirements of this RFP, the City will

respond to all timely questions submitted via e‐mail to the City Contact by the question deadline stated above. Questions

and the responding answers will be sent via e‐mail to all Respondents who have provided an e‐mail address to the City

Contact and will be posted on the City’s web page for this RFP. The City’s failure to timely respond or provide responses

to any questions shall not delay or invalidate the City’s right to make a decision to award an agreement pursuant to this

RFP.

The City will make every reasonable effort to keep Respondents informed about the RFP process. Notifications about

Timeline date changes, amendments to the RFP and other information about the RFP will be sent by e‐mail to

Respondents who have provided an e‐mail address to the City Contact and will be posted on the City’s website for this

RFP. The City’s failure to provide such information shall not delay or invalidate the City’s right to make a decision to

award an agreement pursuant to this RFP.

SCOPE OF SERVICES

The City is seeking the services of a Consultant to perform the following services to implement the Project. Respondent’s

proposal shall address each of the following services, with a separate cost and timeline for each identified task. The

proposal shall address each of the requested services, using the same identifying language, including any paragraph or

section numbers or letters as used in the RFP.

Services will involve providing a full time Project Representative for the duration of project. Staffing typically would

include one or more qualified construction inspector(s) and support staff (office engineering) as needed. If project

personnel are to serve in multiple roles such as Project Manager & Office Engineer, etc. be sure to clearly indicate this

in your staffing table. Please include a project specific organizational flowchart that clearly indicates assigned project

staff and their role(s) with your proposal. The personnel would work under the supervision of a City project manager

and perform technical duties associated with the project. These duties would include but are not limited to observation

of the work, quality assurance & control, submission of daily construction reports & photographs; review of contractor

invoices & change orders; and coordination between the contractor, facility representatives, utility agencies, the public

and the City project manager. The Project Team should have experience with similar scopes of work such as with

historic restoration, masonry building renovations along with familiarity in mechanical & electrical systems. Strong

communication & coordination skills are desired.

3 of 64

Coordination with the Rundel Memorial Library and the City of Rochester Special Events Office will be required to ensure

that construction activities under this contract do not interfere with events that may be impacted by the work in this

contract.

All other duties are as described in the sample Professional Service Agreement for RPR Services included with this RFP.

The Professional Services Agreement that would be used for services performed under this request is located on this

web site labeled as: Sample Professional Services Agreement. The agreement contains a detailed listing of required

Professional Services and deliverables.

PROPOSAL PREPARATION AND SUBMISSION PROCESS

A pre‐bid conference will be held on Tuesday, November 14, 2023 at 10:00 o'clock AM, in the Kussler‐

Cox Auditorium (3rd floor) of the Rundel Memorial Library, at 115 South Avenue, Rochester, New York

14604. Attendance is not required.

Proposals must be received digitally by the City no later than 12:00 PM, Tuesday, 11/28/2023. Proposals shall be

submitted in PDF version to:

Andrew Wojewodzic, Manager of Construction

andrew.wojewodzic@cityofrochester.gov : (585) 428‐6523

This RFP is designed to facilitate the evaluation and selection of a Consultant that is best able to achieve the City’s

objectives. The proposal shall contain a table of contents. All pages shall be numbered and major sections and all

attachments shall be referenced in the table of contents. In order to enable the City to effectively review the

information contained in the proposals, proposals shall reference the numbered and lettered sections of the RFP. The

response to each section shall be clearly indicated and addressed or an explanation provided for why the Respondent is

not submitting a proposal for a specific section or requirement of the RFP. If desired, the proposal may include an

executive summary of no more than two pages.

Each proposal shall be signed by an individual authorized to enter into and execute contracts on the Respondent’s

behalf. Unless otherwise specified in its proposal, Respondent represents that it is capable of meeting or exceeding all

requirements specified in this RFP.

Submission of a proposal shall be deemed authorization for the City to contact Respondent’s references. Evaluation of

proposals will be conducted by the City based on information provided in the Respondent’s proposals and on such other

available information that the City determines to be relevant. The evaluation of proposals may include an on‐site

assessment, meetings with authorized personnel, and may involve the use of a third‐party consultant.

The Respondent selected by the City will be required to enter into a Professional Services Agreement (PSA) with the City

(see Attachment A, the City’s standard PSA form). The establishment of a PSA is contingent upon approval by City

Council for all Agreements in excess of $10,000 or for a period of more than one year and upon the availability of funds

for such an agreement. Unless otherwise stated in the proposal, the Respondent’s response to this RFP shall be deemed

its acceptance of the terms of this PSA.

4 of 64

Note: Attention is directed to the City’s Living Wage requirements and M/WBE and Workforce Utilization Goals.

Utilization plans must be submitted and regular online reporting using B2G Now & LCP Tracker is required. Training is

available upon request by contacting compliance@cityofrochester.gov

Respondents shall provide sufficient information in their written proposals to enable the City review team to make a

recommendation to the Mayor. The City reserves the right to invite any or all Respondents to an interview to discuss

their proposal. Any expenses resulting from such an interview will be the sole responsibility of the Respondent. The

City is under no obligation to select any of the responding Respondents or to conduct the Project described herein. The

City may amend or withdraw the RFP at any time, within its sole discretion. The City shall have no liability for any costs

incurred in preparing a proposal or responding to the City’s requests with respect to the proposal.

PROPOSAL CONTENT

The proposal should include the following information in the order specified:

A. Project statement: A Project narrative that describes the Respondent’s understanding of the City’s needs and

the unique value the Respondent will bring to the process.

B. Description of Services: Methodology the Respondent will use to perform the services required in this RFP. The

proposal should address, in detail, the tasks as described in the Scope of Services, identified by numbered or

lettered sections.

C. Respondent’s Qualifications: Information about the Respondent and its qualifications for this Project. Include

information about prior engagements similar to that being solicited herein by the City. Documented evidence of

the Respondent’s capacity to perform the work, including references, contact names, and phone numbers.

D. Staffing Schedule: An itemized timeline with staff hours which address each of the tasks identified in the Scope

of Services. Clearly indicate the proposed OH&P multiplier & estimated direct reimbursable expenses by item

including the cost of any required Special Inspections & Material Testing. Use of a project management

software for tracking of documents & correspondence is desired. Staffing schedule needs to clearly show hours

for ALL PROPOSED STAFF including any M/WBE personnel. Include a project specific organizational flowchart

of proposed personnel. A not to exceed fee will be negotiated after initial selection of a consultant and will not

be considered in the evaluation process.

E. Project personnel: The name and resume of the Respondent’s lead project representative. Also include names

& resumes, and identify specific roles of all staff who will be involved in the Project. Provide data on the

diversity of Respondent’s workforce, including total number of employees, and percentages of minorities and

females employed.

Subcontractors: Names & resumes, and roles (construction inspection, office engineering, etc.) of sub‐

contractors, associates, or any non‐employees who will be involved in the Project. Material testing services will

be required as a direct reimbursable subcontract. Clearly indicate current M/W/DBE status of subcontractors.

G. Rochester presence: Information about Respondent’s presence in the City of Rochester and/or any collaborative

relationships with local firms that are to be formed for this Project. You must indicate your local office within

the City of Rochester limits to receive bonus points for this category.

5 of 64

This is the opportunity summary page. You are currently viewing an overview of this opportunity and a preview of the attached documentation. For more information, please visit the Publication URL Web page.

Daily notification on new contract opportunities

With GovernmentContracts, you can:

Find more opportunities and win more business
Receive daily alerts for all new bid opportunities
Get contract opportunities matched to your business

ONE WEEK FREE TRIAL

RFP - Professional Construction Management Services for Rundel Memorial Library

Attachment Preview

See also